MULTI-PROJECTS AGREEMENTS FOR ONSHORE/OFFSHORE HVDC CONVERTER STATIONS

RTE réseau de transport d'électricité

RTE intends to launch a call for bid for HVDC VSC onshore converter stations and offshore substations part of 1.2 GW HVDC links at DC operating voltage 320 kV and 2 GW HVDC links at DC operating voltage 525 kV connecting Offshore Wind Farms (OWFs) to the French grid.
RTE intends to enter into Multi-Project Agreement(s) (MPA(s)) with the selected contractors to award by securing the contemplated terms and conditions including the commitments on the availability of manufacturing / construction / installation capacities and delivery dates. Each group of onshore converter stations and offshore substations defined in lots will be subject to a Call-Off procedure and conclusion of the dedicated EPCIC Contract, considered as the further development of MPA(s). Should the Contractor awarded for the MPA(s) be a consortium, each EPCIC Contract may be concluded with all or part of the consortium members. Moreover, the maintenance scope of work may be concluded by a separate contrat.

Date limite

Le délai de réception des offres était de 2023-11-10. L'appel d'offres a été publié le 2023-09-22.

Qui ?

• RTE réseau de transport d'électricité

Qu'est-ce que c'est ?

Où ?

• Ile-de-France › Hauts-de-Seine
• Luxembourg › Luxembourg

Historique des marchés publics

Date	Document
2023-09-22	Avis de marché
2023-11-02	Informations complémentaires
2023-11-29	Informations complémentaires
2024-01-10	Informations complémentaires
2024-11-14	Avis de marché

Avis de marché (2023-09-22)
Objet
Champ d'application du marché
Titre: Ouvrages d'art et de génie civil
Numéro de référence: 23448-1
Brève description:

RTE intends to launch a call for bid for HVDC VSC onshore converter stations and offshore substations part of 1.2 GW HVDC links at DC operating voltage 320 kV and 2 GW HVDC links at DC operating voltage 525 kV connecting Offshore Wind Farms (OWFs) to the French grid. RTE intends to enter into Multi-Project Agreement(s) (MPA(s)) with the selected contractors to award by securing the contemplated terms and conditions including the commitments on the availability of manufacturing / construction / installation capacities and delivery dates. Each group of onshore converter stations and offshore substations defined in lots will be subject to a Call-Off procedure and conclusion of the dedicated EPCIC Contract, considered as the further development of MPA(s). Should the Contractor awarded for the MPA(s) be a consortium, each EPCIC Contract may be concluded with all or part of the consortium members. Moreover, the maintenance scope of work may be concluded by a separate contrat.

Métadonnées de l'avis
Langue originale: anglais 🗣️
Type de document: Avis de marché
Nature du marché: Marché de travaux
Réglementation: Union européenne, avec participation des pays de l'AMP
Vocabulaire commun pour les marchés publics (CPV)
Code: Ouvrages d'art et de génie civil 📦
Code CPV supplémentaire: Ouvrages maritimes 📦
Lieu d'exécution
Région NUTS: France 🏙️

Procédure
Type de procédure: Procédure négociée
Type de soumission: Soumission pour tous les lots
Critères d'attribution
Offre la plus économique

Pouvoir adjudicateur
Identité
Pays: France 🇫🇷
Type de pouvoir adjudicateur: Service d'utilité publique
Nom du pouvoir adjudicateur: RTE Réseau de Transport d'Electricité
Adresse postale: 7C Place du Dôme
Code postal: 92073
Commune postale: Paris la Défense CEDEX
Contact
Adresse Internet: http://www.rte-france.com 🌏
Courrier électronique: magalie.augros@rte-france.com 📧
Téléphone: +33 630614309 📞
URL des documents: https://rtefrance.bravosolution.com/fr/login.html 🌏
URL pour la participation: https://rtefrance.bravosolution.com/fr/login.html 🌏

Référence
Dates
Date d'envoi: 2023-09-22 📅
Date limite de soumission: 2023-11-10 📅
Date de publication: 2023-09-27 📅
Identifiants
Numéro d'avis: 2023/S 186-582003
Numéro JO-S: 186
Informations complémentaires

RTE reserves the right to reduce the scope of the lot and/or options. All communications throughout the tender process related to the Multi Projects Agreement must be sent via project’s e-sourcing platform. Any communications not sent via this e-sourcing portal may not receive any response. RTE will not accept any responsibility in case of occurrence.

Objet
Champ d'application du marché
Brève description:

RTE intends to enter into Multi-Project Agreement(s) (MPA(s)) with the selected contractors to award by securing the contemplated terms and conditions including the commitments on the availability of manufacturing / construction / installation capacities and delivery dates. Each group of onshore converter stations and offshore substations defined in lots will be subject to a Call-Off procedure and conclusion of the dedicated EPCIC Contract, considered as the further development of MPA(s). Should the Contractor awarded for the MPA(s) be a consortium, each EPCIC Contract may be concluded with all or part of the consortium members. Moreover, the maintenance scope of work may be concluded by a separate contrat.

Intitulé du lot: ONSHORE/OFFSHORE HVDC CONVERTER STATIONS 320 kV
Numéro du lot: 1
Brève description:

The scope includes especially the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including onshore civil works and all offshore supporting structure), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Durée de l'accord: 384 mois
Description des options:

- 2 (two) additional offshore substations, to be connected to multi-terminal converter systems described in II.2.4), composed each of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 1.2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms).

- 1 (one) HVDC Voltage Sourced Converter (VSC) converter system in symmetrical monopole configuration operating at DC voltage of 320 kV composed of 1 (one) onshore converter station with capacity of 1.2 GW connected by RTE to the nearest 400kV AC existing substation and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 1.2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms).

The scope includes the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including onshore civil works and all offshore supporting structure), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Informations complémentaires:

RTE reserves the right to reduce the scope of the lot and/or options.

All communications throughout the tender process related to the Multi Projects Agreement must be sent via project’s e-sourcing platform. Any communications not sent via this e-sourcing portal may not receive any response. RTE will not accept any responsibility in case of occurrence.

Intitulé du lot: ONSHORE/OFFSHORE HVDC CONVERTER STATIONS 525 kV
Numéro du lot: 2
Brève description:

- 1 (one) HVDC Voltage Sourced Converter (VSC) converter system in bipole configuration operating at DC voltage of 525 kV composed of 1 (one) onshore converter station with capacity of 2 GW connected by RTE to the nearest 400kV AC existing substation and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms) located in Mediterranean Sea.

The scope includes the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including all offshore supporting structure and onshore civil works), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Description des options:

Informations complémentaires: RTE reserves the right to reduce the scope of the lot and/or option.
Lieu d'exécution
Site principal ou lieu d'exécution: Onshore and Offshore France

Informations juridiques, économiques, financières et techniques
Conditions de participation
Habilitation à exercer l'activité professionnelle:

Details of conditions are described in the PQQ. The PQQ (Pre-Qualification Questionnaire) is available on the RTE e-procurement platform.

Situation économique et financière: Details of conditions are described in the PQQ.
Capacité technique et professionnelle: Selection criteria are set out in the Pre-Qualification Questionnaire (PQQ).
Liste et brève description des règles et critères: Selection criteria are set out in the Pre-Qualification Questionnaire (PQQ).
Exécution du marché
Dépôts et garanties exigés:

Guarantees and bonds will be required, the types and amounts will be defined/prescribed in the Invitation to Tender in compliance to the applicable law.

Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent:

Main financial conditions and payment arrangements will be prescribed in the Invitation to Tender.

Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:

The Candidates may apply as a single Company, Consortium or Joint Venture (JV).

For each lot, a Candidate who will submit an offer as a member of a Consortium or a JV, may not submit an offer as a single Company or with another Consortium or JV.

A Candidate who will submit an offer as a single Company, may not submit an offer as a member of a Consortium or a JV.

Any Candidate that applies as a Consortium or a JV shall, as requested by Article R. 2142-24 of French Code de la Commande Publique, indicate its representative who will represent it with regards to RTE and coordinate its members roles.

The Pre-Qualification Questionnaire (PQQ) shall be filled in for each lot.

Additional conditions may be added to the invitation to tender documentation.

Procédure
Base juridique: 32014L0025
Nombre minimum de candidats: 1
Nombre maximum de candidats: 4
Critères objectifs de sélection du nombre limité de candidats:

Details are described in the Pre-Qualification Questionnaire (PQQ). The PQQ is available on the RTE e-procurement platform (https://rtefrance.bravosolution.com/fr/login.html).

Heure limite de réception des offres: 12:00
Date d'envoi des invitations: 2024-01-09 📅
Langues dans lesquelles les offres ou les demandes de participation peuvent être présentées: anglais 🗣️
Période de validité de l'offre: 6 mois

Pouvoir adjudicateur
Identité
Numéro d'enregistrement national: 444 619 258
Contact
Point de contact: Magalie Augros
Adresse Internet: www.rte-france.com 🌏
Adresse du profil d'acheteur: https://rte-france.bravolution.com 🌏
URL des documents: https://rtefrance.bravosolution.com/fr/login.html 🌏

Référence
Informations complémentaires

For each lot, applicants wishing to participate in the pre-qualification process must provide the Expression of Interest and the Pre-Qualification Questionnaire (PQQ) duly filled in via RTE e--procurement platform including but not limited to:

(i) for single company — company name, main contact name and main contact address completed [in case of Joint Venture (JV) with brief description of JV and its structure] with contemplated list of main sub-contractors if necessary;

(ii) for consortia — brief description of consortium structure, companies names, main contact name and main contact address with contemplated list of main sub-contractors if necessary. The binding letter with all participants signed by each company legal representative with power of attorney.

The main sub-contractors shall be understood as the ones that the construction and/or manufacturing capacities are essential for project and the proposal is based on.

The PQQ, which is available on the RTE e-procurement platform, is a questionnaire divided into general questions regarding the applicants and more specific questions regarding the applicants experience relevant to the scope of the project as well as health and safety policies and experiences.

RTE reserves its right to exclude Joint Venture/consortium applicants that would change their composition partway through the process without prior approval from RTE. Any change in the form and/or composition of the single company or consortium at any point of the procedure shall be prior-approved in writing by RTE.

Applicant shall note that for certain aspects of the work, tenderer(s) may be required to select sub-contractors from existing RTE qualification system and/or use the pre-approved sub-contractors’ details of which will be set-out in the ITT or during tendering process.

Applicants shall note that the aspects and proposed solutions for social insertion criteria may be set-out in the ITT and will be part of award criteria.

Informations complémentaires
Organe de révision
Nom: Tribunal de Grande Instance de Nanterre
Adresse postale: 179-191 avenue Joliot-Curie
Commune postale: Nanterre
Code postal: 92020
Pays: France 🇫🇷
Téléphone: +33 140971010 📞
Fax: +33 147243161 📠
Informations sur les délais d'introduction des recours:

A claim in a contractual summary proceeding is possible as stated in articles 11 et seq. of Order No 2009-515 of 7.5.2009 related to complaint proceedings applicable to public procurement contracts.

The claim must be lodged at the latest on the thirty first (31st) day following the publication of the contract award notice in the Official Journal of the European Union or, for the contracts based on a framework agreement or on a dynamic purchasing system, following the notification of the contract signature. In the absence of publication of the award notice or in the absence of notification of the contract signature, an application to the competent court may be made until the expiry of a six (6) month period starting at the day after the date of conclusion of the contract in accordance with article 1441-3 of the French Code of Civil Procedure.

Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Adresse postale: 179-191, avenue Joliot-Curie
Source: OJS 2023/S 186-582003 (2023-09-22)

Informations complémentaires (2023-11-02)
Objet
Métadonnées de l'avis
Type de document: Informations complémentaires
Vocabulaire commun pour les marchés publics (CPV)
Code: Travaux d'assemblage d'ossatures métalliques d'ouvrage 📦

Référence
Dates
Date d'envoi: 2023-11-02 📅
Date limite de soumission: 2023-12-20 📅
Date de publication: 2023-11-07 📅
Identifiants
Numéro d'avis: 2023/S 214-675381
Se réfère à l'avis: 2023/S 186-582003
Numéro JO-S: 214
Source: OJS 2023/S 214-675381 (2023-11-02)

Informations complémentaires (2023-11-29)
Référence
Dates
Date d'envoi: 2023-11-29 📅
Date limite de soumission: 2024-01-15 📅
Date de publication: 2023-12-04 📅
Identifiants
Numéro d'avis: 2023/S 233-732796
Numéro JO-S: 233
Informations complémentaires

Pursuant to Article 28§6 of Regulation (EU) 2022/2560 of 14 December 2022 on foreign subsidies distorting the internal market, Candidates are informed that they are under the notification or declaration’s obligation as set out in Article 29 of said Regulation

Source: OJS 2023/S 233-732796 (2023-11-29)

Informations complémentaires (2024-01-10)
Référence
Dates
Date d'envoi: 2024-01-10 📅
Date limite de soumission: 2024-02-01 📅
Date de publication: 2024-01-15 📅
Identifiants
Numéro d'avis: 2024/S 010-024322
Numéro JO-S: 10
Source: OJS 2024/S 010-024322 (2024-01-10)

Avis de marché (2024-11-14)
Objet
Champ d'application du marché
Titre: Multi-projects agreements for onshore/offshore hvdc converter stations
Numéro de référence: 23448-1
Brève description:

RTE intends to launch a call for bid for HVDC VSC onshore converter stations and offshore substations part of 1.2 GW HVDC links at DC operating voltage 320 kV and 2 GW HVDC links at DC operating voltage 525 kV connecting Offshore Wind Farms (OWFs) to the French grid. RTE intends to enter into Multi-Project Agreement(s) (MPA(s)) with the selected contractors to award by securing the contemplated terms and conditions including the commitments on the availability of manufacturing / construction / installation capacities and delivery dates. Each group of onshore converter stations and offshore substations defined in lots will be subject to a Call-Off procedure and conclusion of the dedicated EPCIC Contract, considered as the further development of MPA(s). Should the Contractor awarded for the MPA(s) be a consortium, each EPCIC Contract may be concluded with all or part of the consortium members. Moreover, the maintenance scope of work may be concluded by a separate contrat.

Type de contrat: Marché de travaux
Produits/services: Ouvrages d'art et de génie civil 📦
Autres restrictions s’appliquant au lieu d’exécution: N’importe où dans le pays donné
Informations sur les lots
Ce contrat est divisé en lots ✅
Les offres peuvent être présentées pour un nombre maximal de lots: 2

1️⃣
Identifiant interne: 23448-1 - Lot 1
Titre: ONSHORE/OFFSHORE HVDC CONVERTER STATIONS 320 kV
Description du marché:

2 (two) multi-terminal HVDC Voltage Sourced Converter (VSC) converter systems in symmetrical monopole configuration operating at DC voltage of 320 kV composed each of 2 (two) onshore converter stations (one in Gironde and one in Loire-Atlantique) with capacity of 1.2 GW connected by RTE to the nearest 400kV AC existing substation located respectively in Gironde and Loire-Atlantique and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 1.2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms). The scope includes especially the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including onshore civil works and all offshore supporting structure), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Informations complémentaires:

Produits/services supplémentaires:

Ouvrages maritimes 📦

Services d'ingénierie 📦

Services d'installation offshore 📦

+ 11 de plus

Services de conception technique 📦

Services de maintenance préventive 📦

Services de réparation et d'entretien 📦

Services de réparation et d'entretien d'installations électriques et mécaniques de bâtiment 📦

Services offshore 📦

Travaux d'assemblage d'ossatures métalliques d'ouvrage 📦

Travaux de construction d'installations pour plate-formes 📦

Travaux de fabrication de modules offshore 📦

Travaux de fabrication de treillis de plate-forme 📦

Travaux de montage offshore 📦

Travaux de montage à terre 📦

Site principal ou lieu d'exécution: Onshore and Offshore France
Pays: France 🇫🇷
Durée de l'accord: 384 mois
Nombre maximum de reconductions: 0
Informations sur les options
Options ✅
Description des options:

According to article R2122-7 of the French code de la commande publique, new works that are similar to works previously awarded to a contractor in compliance with the relevant advertising and competition rules, can be awarded to the same contractor without issuing a new call for tender ("sans publicité ni mise en concurrence préalables"). RTE reserves the right to conclude as options the following similar procurement contracts: - 2 (two) additional offshore substations, to be connected to multi-terminal converter systems described in II.2.4), composed each of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 1.2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms). - 1 (one) HVDC Voltage Sourced Converter (VSC) converter system in symmetrical monopole configuration operating at DC voltage of 320 kV composed of 1 (one) onshore converter station with capacity of 1.2 GW connected by RTE to the nearest 400kV AC existing substation and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 1.2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms). The scope includes the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including onshore civil works and all offshore supporting structure), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Informations sur les variantes
Les variantes sont acceptées ✅
Informations sur les limites du nombre de candidats à inviter
Nombre minimum envisagé: 1
Nombre maximum: 4
Critères d'attribution
Prix ✅
Titre
Numéro d'identification du lot: LOT-0001

2️⃣
Identifiant interne: 23448-1 - Lot2
Titre: ONSHORE/OFFSHORE HVDC CONVERTER STATIONS 525 kV
Description du marché:

- 2 (two) HVDC Voltage Sourced Converter (VSC) converter systems in bipole configuration operating at DC voltage of 525 kV composed each of 1 (one) onshore converter station with capacity of 2 GW connected by RTE to the nearest 400kV AC existing substation located in Normandie and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms). - 1 (one) HVDC Voltage Sourced Converter (VSC) converter system in bipole configuration operating at DC voltage of 525 kV composed of 1 (one) onshore converter station with capacity of 2 GW connected by RTE to the nearest 400kV AC existing substation and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms) located in Mediterranean Sea. The scope includes the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including all offshore supporting structure and onshore civil works), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Informations complémentaires:

RTE reserves the right to reduce the scope of the lot and/or option. All communications throughout the tender process related to the Multi Projects Agreement must be sent via project’s e-sourcing platform. Any communications not sent via this e-sourcing portal may not receive any response. RTE will not accept any responsibility in case of occurrence. Minimum time frame during which the tenderer must maintain the tender is 6 months.

Produits/services supplémentaires:

Ouvrages maritimes 📦

Services d'ingénierie 📦

Services d'installation offshore 📦

+ 11 de plus

Services de conception technique 📦

Services de maintenance préventive 📦

Services de réparation et d'entretien 📦

Services de réparation et d'entretien d'installations électriques et mécaniques de bâtiment 📦

Services offshore 📦

Travaux d'assemblage d'ossatures métalliques d'ouvrage 📦

Travaux de construction d'installations pour plate-formes 📦

Travaux de fabrication de modules offshore 📦

Travaux de fabrication de treillis de plate-forme 📦

Travaux de montage offshore 📦

Travaux de montage à terre 📦

Informations sur les options
Description des options:

According to article R2122-7 of the French code de la commande publique, new works that are similar to works previously awarded to a contractor in compliance with the relevant advertising and competition rules, can be awarded to the same contractor without issuing a new call for tender ("sans publicité ni mise en concurrence préalables"). RTE reserves the right to conclude as an option the following similar procurement contract: - 1 (one) HVDC Voltage Sourced Converter (VSC) converter system in bipole configuration operating at DC voltage of 525 kV composed of 1 (one) onshore converter station with capacity of 2 GW connected by RTE to the nearest 400kV AC existing substation and 1 (one) offshore substation composed of 1 (one) offshore converter platform and 1 (one) offshore converter station with capacity of 2 GW including the AC switchgear to connect to the grid OWFs (Offshore Wind Farms). The scope includes the design (including detailed design), engineering, procurement, manufacturing, supply, transportation, installation, construction (including onshore civil works and all offshore supporting structure), testing, onshore and offshore commissioning, spares provision, operational handover, warranty and maintenance.

Titre
Numéro d'identification du lot: LOT-0002

Procédure
Type de procédure
Procédure négociée avec mise en concurrence préalable ✅
Base juridique: Directive 2014/25/UE
Informations administratives
Langues dans lesquelles les offres ou les demandes de participation peuvent être présentées: anglais 🗣️
Date estimée d'envoi des invitations à soumissionner ou à participer aux candidats sélectionnés: 2024-03-01 📅
Informations sur la réduction du nombre de solutions ou d'offres au cours de la négociation ou du dialogue
Recours à une procédure par étapes pour réduire progressivement le nombre de solutions à discuter ou d'offres à négocier ✅
Conditions de passation du marché
Une garantie est requise ✅
Forme juridique soumissionnaire ✅
Date limite de réception des demandes de participation/candidatures: 2024-02-01 12:00:00 📅
Le marché contient des conditions d'exécution ✅
Un accord de non-divulgation est requis ✅
Le marché est soumis aux obligations du règlement 2022/2560 sur les subventions étrangères ✅

Informations juridiques, économiques, financières et techniques
Conditions de participation
Critère de sélection: Inscription à un registre professionnel pertinent
Liste et brève description des règles et critères:

The exhaustive list of selection criteria is provided in the PQQ (Pre-Qualification Questionnaire). The PQQ is available on the RTE e-procurement platform.

Critère de sélection: Autres exigences économiques ou financières
Références sur des travaux spécifiés
Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:

The Candidates may apply as a single Company, Consortium or Joint Venture (JV). For each lot, a Candidate who will submit an offer as a member of a Consortium or a JV, may not submit an offer as a single Company or with another Consortium or JV. A Candidate who will submit an offer as a single Company, may not submit an offer as a member of a Consortium or a JV. Any Candidate that applies as a Consortium or a JV shall, as requested by Article R. 2142-24 of French Code de la Commande Publique, indicate its representative who will represent it with regards to RTE and coordinate its members roles. The Pre-Qualification Questionnaire (PQQ) shall be filled in for each lot. Additional conditions may be added to the invitation to tender documentation.

Dépôts et garanties exigés:

Guarantees and bonds will be required, the types and amounts will be defined/prescribed in the Invitation to Tender in compliance to the applicable law.

Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent:

Main financial conditions and payment arrangements will be prescribed in the Invitation to Tender.

Conditions liées au contrat
Conditions d'exécution du contrat: Contractual conditions will be specified under the Invitation to Tender.
Conditions de participation
Motif d'exclusion: Manquement à des obligations liées à des motifs d’exclusion purement nationaux

Pouvoir adjudicateur
Nom et adresse
Nom: RTE Réseau de Transport d'Electricité
Numéro d'enregistrement national: 444 619 258 02482
Département: Direction des Achats
Adresse postale: 7C Place du Dôme
Code postal: 92073
Commune postale: Paris la Défense CEDEX
Région: Hauts-de-Seine 🏙️
Pays: France 🇫🇷
Point de contact: Magalie Augros
Courrier électronique: magalie.augros@rte-france.com 📧
Téléphone: +33 630614309 📞
URL: www.rte-france.com 🌏
Adresse du profil d'acheteur: https://rte-france.bravolution.com 🌏
Type de pouvoir adjudicateur
Organisme de droit public
Activité principale
Électricité
Communication
URL de participation: https://rtefrance.bravosolution.com 🌏
Le nombre de candidats à inviter pour la seconde étape de la procédure est limité ✅
Les critères seront appliqués pour sélectionner les candidats à inviter pour la seconde étape de la procédure ✅
Justification de la restriction de l’accès à certains documents de marché: Protection des informations particulièrement sensibles
L'accès aux documents d'appel d'offres est restreint
Soumission par voie électronique: Requise

Informations complémentaires
Informations complémentaires

The contract notice is under French law. The time for this contract notice is the French time. The applicable law of the future contracts will be French law. Official communications shall be conducted via the message board of RTE e-procurement platfom, namely https://rte-france.bravosolution.com. For each lot, applicants wishing to participate in the pre-qualification process must provide the Expression of Interest and the Pre-Qualification Questionnaire (PQQ) duly filled in via RTE e--procurement platform including but not limited to: (i) for single company — company name, main contact name and main contact address completed [in case of Joint Venture (JV) with brief description of JV and its structure] with contemplated list of main sub-contractors if necessary; (ii) for consortia — brief description of consortium structure, companies names, main contact name and main contact address with contemplated list of main sub-contractors if necessary. The binding letter with all participants signed by each company legal representative with power of attorney. The main sub-contractors shall be understood as the ones that the construction and/or manufacturing capacities are essential for project and the proposal is based on. The PQQ, which is available on the RTE e-procurement platform, is a questionnaire divided into general questions regarding the applicants and more specific questions regarding the applicants experience relevant to the scope of the project as well as health and safety policies and experiences. RTE reserves its right to exclude Joint Venture/consortium applicants that would change their composition partway through the process without prior approval from RTE. Any change in the form and/or composition of the single company or consortium at any point of the procedure shall be prior-approved in writing by RTE. Applicant shall note that for certain aspects of the work, tenderer(s) may be required to select sub-contractors from existing RTE qualification system and/or use the pre-approved sub-contractors’ details of which will be set-out in the ITT or during tendering process. Applicants shall note that the aspects and proposed solutions for social insertion criteria may be set-out in the ITT and will be part of award criteria.

Informations complémentaires

Organe de révision
Nom: Tribunal Judiciaire de Nanterre
Numéro d'enregistrement national: 123456
Département: Instance chargée des procédures de recours
Région: Hauts-de-Seine 🏙️
Point de contact: Instance chargée des procédures de recours
Courrier électronique: accueil.tj-nanterre@justice.fr 📧
URL: www.cours-appel.justice.fr/versailles/tribunal-judiciaire-de-nanterre 🌏
Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Adresse postale: 179-191 avenue Joliot-Curie
Procédure d'examen
Informations précises sur le(s) délai(s) des procédures d'examen:

A claim in a precontractual summary proceeding is possible as stated in articles 5 et seq. of Order No 2009-515 of 7.5.2009 related to complaint proceedings applicable to public procurement contracts. The claim must be lodged before the conclusion of the contract. A claim in a contractual summary proceeding is possible as stated in articles 11 et seq. of Order No 2009-515 of 7.5.2009 related to complaint proceedings applicable to public procurement contracts. The claim must be lodged at the latest on the thirty first (31st) day following the publication of the contract award notice in the Official Journal of the European Union or, for the contracts based on a framework agreement or on a dynamic purchasing system, following the notification of the contract signature. In the absence of publication of the award notice or in the absence of notification of the contract signature, an application to the competent court may be made until the expiry of a six (6) month period starting at the day after the date of conclusion of the contract in accordance with article 1441-3 of the French Code of Civil Procedure.

Changements
Texte à corriger dans l'avis original
Numéro d'identification du lot: LOT-0001
Nouvelle valeur
Texte: The Lot 0001 - Onshore/Offshore HVDC Converter Stations 320kV is cancelled.
Autres informations complémentaires
The Lot 0001 - Onshore/Offshore HVDC Converter Stations 320kV is cancelled.
Principale raison du changement: Correction par l’acheteur
Informations sur les modifications
Version de l’avis antérieur à modifier: 582003-2023
Source: OJS 2024/S 223-697464 (2024-11-14)

Nouveaux marchés dans des catégories connexes 🆕

Travaux de construction (>20 nouveaux marchés)

Travaux de construction complète ou partielle et travaux de génie civil (>20)

Ouvrages d'art et de génie civil (>20)