Construction of the Base Tunnel of the Lyon-Turin Railway Link Cross Border Section from the Access Sites on the Italian Side and Reuse of Excavated Earth and Rocks
Under the new Lyon-Turin railway link project, TELT company, as a contracting entity, is the public developer in charge of building and managing the cross-border section of the future infrastructure.
The aim of this public procurement contract is to carry out construction works on operational worksites No 3 (boring of the base tunnel from the Chiomonte site, direction Susa), No 4 (boring of the base tunnel from the Chiomonte site, direction France) and No 10 (reclamation of the earth and rocks excavated from all sites on Italian territory).
Each lot of this public procurement contract is a mixed single-contractor framework contract, i.e. a framework contract with purchase orders and follow-on contracts.
Date limite
Le délai de réception des offres était de 2019-09-16.
L'appel d'offres a été publié le 2019-06-26.
Fournisseurs
Les fournisseurs suivants sont mentionnés dans les décisions d'attribution ou dans d'autres documents relatifs aux marchés publics :
Objet Champ d'application du marché
Titre:
“Construction of the Base Tunnel of the Lyon-Turin Railway Link Cross Border Section from the Access Sites on the Italian Side and Reuse of Excavated Earth...”
Titre
Construction of the Base Tunnel of the Lyon-Turin Railway Link Cross Border Section from the Access Sites on the Italian Side and Reuse of Excavated Earth and Rocks
T13
Afficher plus
Produits/services: Travaux de construction de tunnels ferroviaires📦
Brève description:
“Under the new Lyon-Turin railway link project, TELT company, as a contracting entity, is the public developer in charge of building and managing the...”
Brève description
Under the new Lyon-Turin railway link project, TELT company, as a contracting entity, is the public developer in charge of building and managing the cross-border section of the future infrastructure.
The aim of this public procurement contract is to carry out construction works on operational worksites No 3 (boring of the base tunnel from the Chiomonte site, direction Susa), No 4 (boring of the base tunnel from the Chiomonte site, direction France) and No 10 (reclamation of the earth and rocks excavated from all sites on Italian territory).
Each lot of this public procurement contract is a mixed single-contractor framework contract, i.e. a framework contract with purchase orders and follow-on contracts.
Afficher plus Informations sur les lots
Des offres peuvent être soumises pour tous les lots
1️⃣ Champ d'application du marché
Titre:
“Operational worksites 3 and 4 (CO3 and CO4): construction of the base tunnel on the Italian side from the Chiomonte site, by TBM (CO3) and conventional method (CO4)”
Titre
Operational worksites 3 and 4 (CO3 and CO4): construction of the base tunnel on the Italian side from the Chiomonte site, by TBM (CO3) and conventional method (CO4)
Afficher plus Titre
Numéro d'identification du lot: 1
Description
Produits/services supplémentaires: Travaux de construction de tunnels ferroviaires📦
Lieu d'exécution: Piemonte 🏙️
Site principal ou lieu d'exécution: Communes of Chiomonte and Salbertrand.
Description du marché:
“The works in this Lot 1 include the transfer of existing structures (in particular the Maddalena 1 gallery and its installations, as well as all areas and...”
Description du marché
The works in this Lot 1 include the transfer of existing structures (in particular the Maddalena 1 gallery and its installations, as well as all areas and installations at the Chiomonte site) and the construction of all future structures for the base tunnel, each tube being approximately 9,5 km long, from the boundaries of operational worksite 5 (CO5: boring of the base tunnel from the Villarodin-Bourget/Modane drift) up to the East entrance of the base tunnel in Susa.
The works that may be carried out by means of purchase orders are as follows:
— preparatory site works in the Colombera zone to extend the present La Maddalena area on the left bank of the Clarea river (fences, security installations, earthwork, backfilling, interface development, electric power supply, site ventilation, ancillary installations, living quarters, areas for temporary storage of excavation materials, etc.),
— construction surveys for tunnel structures,
— construction surveys and performance of all environmental surveillance and materials checking services,
— work systems and security costs according to the legislative decree 81/08,
— construction of the structures at the entrance to the Maddalena 2 decline,
— boring of the Maddalena 2 decline by TBM,
— construction by conventional method of the cavern used to assemble the TBM to excavate the odd line of the base tunnel,
— excavation by conventional method of the Maddalena 1 — Clarea security area interconnection tunnel, and of the Maddalena 2 — Clarea security area interconnection tunnel,
— excavation by TBM of the 2 base tunnel tubes (even and odd lines),
— construction of the Clarea security area and of the caverns to assembly the TBMs for the CO5 operational worksite,
— transport of excavated materials to the Salbertrand reclamation site,
— construction of the facility to prefabricate tunnel segments in the Salbertrand area, prefabrication and transportation of segments to line the 2 tubes of the base tunnel,
— construction of the Maddalena 1 bis tunnel to store the greenstone,
— final securing of the excavated greenstone for the construction of the base tunnel, in the Maddalena 1 and Maddalena 1 bis tunnels,
— construction of the structures at the East entrance of the base tunnel in Susa,
— winding down of the work site and renovation of the sites in the La Maddalena and Salbertrand areas.
The works that may be performed by means of follow-on contracts (launched or not depending on the CO5 completion date) consist of so-called ‘counter-attack’ services for the excavation of the base tunnel on the La Clarea site towards France, which may include all or part of the following services:
— construction surveys for the counter-attack operation, including moving the caverns to dismantle the TBMs used for the CO5 operational worksite,
— excavation of the base tunnel as part of the counter-attack.
Follow-on contracts may as well allow for civil works to be carried out to construct tunnel structures that will interface with future equipment contracts.
The scope of this ‘Operational worksite 3/4’ lot may undergo minor changes at the limits of ‘Operational worksite 5’ to the West, based on the actual progress of each worksite and the need to comply with the projected project implementation programme schedule.
The duration mentioned in II.2.7) is the period of time during which the purchase orders and follow-on contracts may be issued. The tentative duration for the execution of works (outside the preparation and warranty periods) is of 81 months for Lot 1. A contractually binding performance deadline will be set for each purchase order or follow-on contract.
Afficher plus Critères d'attribution
Le prix n'est pas le seul critère d'attribution et tous les critères ne sont énoncés que dans les documents de passation de marchés
Champ d'application du marché
Valeur totale estimée hors TVA: EUR 808 025 000 💰
Durée du contrat, de l'accord-cadre ou du système d'acquisition dynamique
Le délai ci-dessous est exprimé en nombre de mois.
Description
Durée de l'accord: 108
Informations sur les variantes
Les variantes sont acceptées ✅ Champ d'application du marché
Informations sur les fonds de l'Union européenne: TENT-T (Trans-European Transport Network): project n. 2014-EU-TM-0401-M
Description
Informations complémentaires:
“The framework contract of this Lot No 1 shall be concluded without any minimum or maximum amount. The estimated amount mentioned in II.2.6) above is not...”
Informations complémentaires
The framework contract of this Lot No 1 shall be concluded without any minimum or maximum amount. The estimated amount mentioned in II.2.6) above is not contractually binding. This is merely an estimate based on a base tunnel section length of approximately 9,5 km.
2️⃣ Champ d'application du marché
Titre:
“Operational Worksite 10: Reclamation Works on Earth and Rock Excavated from all Worksites Located on Italian Territory, and Environmental Requalification Works” Titre
Numéro d'identification du lot: 2
Description
Produits/services supplémentaires: Ouvrages ferroviaires📦
Produits/services supplémentaires: Travaux de construction d'usines de traitement des déchets📦
Site principal ou lieu d'exécution: Communes of Chiomonte, Salbertrand, Caprie and Torrazza.
Description du marché:
“The works in this Lot 2 include the transfer of existing structures, construction of the railway platforms to load and unload excavation materials for...”
Description du marché
The works in this Lot 2 include the transfer of existing structures, construction of the railway platforms to load and unload excavation materials for transportation by rail, and the construction of reclamation installations for the materials excavated from operational worksites 1, 3 and 4, to produce:
— CE aggregates for concrete to be reused in operational worksite 1 (CO1: Bussoleno tunnel), operational worksite 2 (CO2: Susa plain) and operational worksite 3/4 (CO3/04: base tunnel),
— backfill materials to be mainly reused for CO2,
— environmental requalification materials (Caprie and Torrazza sites).
The works that may be carried out by means of purchase orders are as follows:
— construction surveys for all platforms, installations and structures concerning this operational worksite 10,
— construction surveys and performance of all environmental monitoring and materials checking services,
— work systems and security costs according to legislative decree 81/08,
— construction of the railway platforms at Salbertrand, Caprie and Torrazza,
— construction of reclamation installations,
— full management of excavation materials according to Italian legislation,
— railway transportation of the reclaimed materials from Salbertrand to the Caprie and Torrazza depots,
— storage of reclaimed materials.
The works that may be performed by means of possible follow-on contracts (launched or not depending on the date pollution clean-up operations are carried out by third parties) consist of designing and executing pollution clean-up work on any contaminated zones required for the project.
The scope of this ‘Operational worksite 10’ lot may undergo minor changes at the limits of ‘Operational worksite 4’ to the West, based on the actual progress of each of the worksites and the need to comply with the projected project implementation programme schedule.
It is to be noted that transportation of materials by rail must be managed by authorised companies in Italy in line with the ASNF directive.
The duration mentioned in II.2.7) is the period of time during which the purchase orders and follow-on contracts may be issued. The tentative duration for the execution of works (outside the preparation and warranty periods) is of 81 months for lot 2. A contractually binding performance deadline will be set for each purchase order or follow-on contract.
Afficher plus Champ d'application du marché
Valeur totale estimée hors TVA: EUR 216 440 000 💰
Description
Informations complémentaires:
“The framework contract on this Lot No 2 shall be concluded without any minimum or maximum amount. The estimated amount mentioned in II.2.6) is not...”
Informations complémentaires
The framework contract on this Lot No 2 shall be concluded without any minimum or maximum amount. The estimated amount mentioned in II.2.6) is not contractually binding. It is merely an estimate based on a base tunnel section length of approximately 9,5 km and on the Bussoleno tunnel section length of approximately 2 km.
Informations juridiques, économiques, financières et techniques Conditions de participation
Liste et brève description des conditions:
“Each economic operator, acting alone or in a consortium must present:
— either forms DC1 and DC2 or their equivalents, freely available at the following...”
Liste et brève description des conditions
Each economic operator, acting alone or in a consortium must present:
— either forms DC1 and DC2 or their equivalents, freely available at the following address: http://www.economie.gouv.fr/daj/formulaires-declaration-du-candidat (in case of consortium/venture, the DC1 form must be provided only by the consortium/venture representative), or
— the European Single Procurement Document (ESPD), or their equivalents for bidders that are not based in European Union; it must be noted that TELT does not authorise candidates to solely mention in the European Single Procurement Document or the equivalent that they are equipped with the required skills and capabilities without providing specific details of the same.
Economic operators subject to the Italian law will also have to provide the following documents:
— the social security contributions payment certificate (DURC),
— the ‘protocollo operativo per il Monitoraggio finanziario delle Grandi Opere (MGO)’ filled form, available at the following address: http://www.telt-sas.com/it/fornitori/
Particular attention shall be paid to potential conflicts of interest which could arise between providers performing construction surveys for the works pertaining to this public contract and the holders of the following contracts awarded by TELT: assistance to the project sponsor and studies during the works phase (AMO); safety and health protection coordination (CSPS) on the Italian side; technical control services with respect to administrative and functional aspects and structure stability (collaudo) for the underground operational projects on the Italian side; design and management of the Environmental Monitoring Plan (PMA); implementation of the Environmental Monitoring Plan (EMA); environmental coordination services on the Italian side; project management services for construction of the base tunnel from the work sites in Italian territory (CO3/4); project management services for the management and use of excavated materials on the Italian side (CO10).
Afficher plus Situation économique et financière
Liste et brève description des critères de sélection:
“Each economic operator, acting alone or in a consortium/venture, must prove that it has the required economic, asset and financial capabilities by...”
Liste et brève description des critères de sélection
Each economic operator, acting alone or in a consortium/venture, must prove that it has the required economic, asset and financial capabilities by presenting the following:
— certified financial statements (including income statement and, for French candidates, tax form and annexes) available for financial years 2015, 2016 and 2017, or equivalent for non-French candidates,
— a filled copy of the Excel file ‘bilans financiers’ (financial statements), in Excel format, available at the following address: https://telt.achatpublic.com/accueil
— a valid insurance certificate for occupational risks specifying the guaranteed capital value.
“The minimum annual turnover required of 1 candidate for each of the 3 years 2015, 2016 and 2017 (for consortiums/ventures, this should be understood as the...”
The minimum annual turnover required of 1 candidate for each of the 3 years 2015, 2016 and 2017 (for consortiums/ventures, this should be understood as the cumulative turnover of all members and, eventually, that of the contractors involved alongside the candidate whatever their legal ties) is:
— 178 000 000 EUR excl. taxes for Lot No 1 (operational worksite 3/4),
— 30 000 000 EUR excl. taxes for Lot No 2 (operational worksite 10).
The turnover means to the turnover available according to accessible data, based on the foundation date of the company or on the starting date of activities for an economic operator. If the candidate is unable to provide the turnover required, it will be allowed to prove its financial capacities via any other document recognised as an equivalent.
Afficher plus Capacité technique et professionnelle
Liste et brève description des critères de sélection:
“Each economic operator, acting alone or as a consortium/venture, must demonstrate it has sufficient technical and professional capabilities by providing:
1)...”
Liste et brève description des critères de sélection
Each economic operator, acting alone or as a consortium/venture, must demonstrate it has sufficient technical and professional capabilities by providing:
1) Human and material resources:
— a declaration of its annual average staff headcount and the size of its managerial staff (executive manager and middle manager) for the 3 years 2016, 2017 and 2018,
— a description of the tools and equipment it shall use to execute this framework contract.
2) Professional references:
— a list of projects it has executed over the last 10 years.
3) Quality certifications:
— its quality certificates (e.g. ISO 9001, 14001, OHSAS 18001 or ISO 45001, ISO/CEI 27001 or equivalents).
Afficher plus Conditions de participation
Conditions de participation (capacités techniques et professionnelles):
“As far as professional references are concerned, the candidate must provide at least 1 current reference or obtained within the last 10 years for each of...”
Conditions de participation (capacités techniques et professionnelles)
As far as professional references are concerned, the candidate must provide at least 1 current reference or obtained within the last 10 years for each of the following components of the following work items (in case of consortiums/ventures, 1 reference per consortium is sufficient):
Lot No 1 (operational worksite 3/4):
— construction surveys for 1 single underground construction with a minimum value of 100 000 000 EUR,
— construction of a tunnel with a cover of more than 500 m,
— construction of a cavern with a section in excess of 250 m,
— construction of a tunnel by mechanised excavation with simultaneous lining using prefabricated segments in geologically heterogeneous environments and with a pressurised front,
— construction of a tunnel excavated in rock using the conventional method with an excavated section of at least 60 m,
— cut-and-cover civil works over a length of at least 50 m with an interior section of at least 40 m,
— earthworks in the presence of water with treatment of water infiltration (such as water plugs, soil injection or pumping),
— management of a stock of over 200 000 m of materials.
Lot No 2 (operational worksite 10):
— construction surveys for the railway platforms,
— design and construction of installations to prepare excavation materials for reuse,
— construction of railway platforms in the presence of rail traffic,
— own management or management by authorised companies of the rail transportation of goods and/or loads,
— reclamation of excavation materials for volumes in place of at least 500 000 m,
— management of a stock of over 200 000 m of materials.
Candidates are not allowed to provide more than 3 references per item. If they provide more than 3 references, only the first 3 listed will be considered.
Each reference must be presented using the table available on TELT’s dematerialisation platform (http://telt.achatpublic.com/accueil/). This table, to be submitted in Excel format, containing information pertaining to the candidate's role, turnover share and scope of technical services of each economic operator concerned, as well as the specific addresses of the clients concerned, should be provided with certificates of satisfactory performance, if possible.
If the candidate is unable to provide the proof of technical and professional abilities required, it will be allowed to prove them via any other document recognised as an equivalent.
Afficher plus
Liste et brève description des règles et critères:
“Candidates will be selected on the basis of their economic, financial, technical and professional abilities, according to the documents provided with their...”
Liste et brève description des règles et critères
Candidates will be selected on the basis of their economic, financial, technical and professional abilities, according to the documents provided with their bids, and after the exclusion of all candidatures judged inadmissible.
Afficher plus
Dépôts et garanties exigés:
“A contract holdback of 5 % of the value of the service shall be applied to each purchase order and follow-on contract. This holdback may be replaced at the...”
Dépôts et garanties exigés
A contract holdback of 5 % of the value of the service shall be applied to each purchase order and follow-on contract. This holdback may be replaced at the holder's discretion with a first-demand guarantee. The holder shall not replace it with a joint and personal guarantee.
Afficher plus
Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent:
“This framework contract is financed by the European Union, Italy and France. Payments for services shall be made by bank transfer within 45 days from the...”
Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent
This framework contract is financed by the European Union, Italy and France. Payments for services shall be made by bank transfer within 45 days from the date of receipt of the related invoice. Each purchase order shall be based on unit prices that will be adjusted, each follow-on contract shall be based on lump sums or unit prices that may be adjusted or not.
Afficher plus
Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:
“Candidates may bid as individual companies or as consortiums/ventures. For each lot, the same legal person shall neither submit an application both...”
Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché
Candidates may bid as individual companies or as consortiums/ventures. For each lot, the same legal person shall neither submit an application both individually and as a member of a consortium/venture, nor as a member of several consortiums/ventures. Once the contract is awarded, the form of consortium/venture required by TELT shall be the mixed form with a jointly-liable representative. The mixed form is justified by the diversity of the skills requested and the missions required, both of which are highly specialised: each of the co-contractors must therefore be committed solely to the component of the contract it is engaged to carry out. As to the representative's joint liability, it allows for the satisfactory performance of the whole service to be guaranteed and for remedial measures to be offered to the project owner, should any co-contractor default on its obligation.
Afficher plus Conditions liées au contrat
Conditions d'exécution du contrat:
“Authorisations from the administration relative to site facilities, utilities, transportation, execution of works 24/7, employment of workers, and use of...”
Conditions d'exécution du contrat
Authorisations from the administration relative to site facilities, utilities, transportation, execution of works 24/7, employment of workers, and use of explosives shall be required. The contract holder shall take all steps necessary to obtain these documents from all competent authorities.
This framework contract will also contain an employment promotion clause aimed at facilitating the professional integration of disadvantaged persons (number of working hours required from targeted persons). It will also be subject to the provisions of the Italian Regional Act 4/2011 — ‘Worksites, development and the territory’ — and the Act's corresponding employment and environment protocols implemented.
Procédure Type de procédure
Procédure négociée avec mise en concurrence préalable
Informations sur un accord-cadre ou un système d'acquisition dynamique
Accord-cadre avec un seul opérateur
Description
Dans le cas d'accords-cadres, justifier toute durée supérieure à 8 ans:
“For each lot, the framework contract period is above 8 years because, in addition to the effective works duration, it also includes the underground work...”
Dans le cas d'accords-cadres, justifier toute durée supérieure à 8 ans
For each lot, the framework contract period is above 8 years because, in addition to the effective works duration, it also includes the underground work preparation timeframe, the possible hazards deriving from the variable nature of the subsoils encountered during digging, as well as timeframes for works acceptance and guarantee period.
Afficher plus Informations administratives
Délai de réception des offres ou des demandes de participation: 2019-09-16
14:00 📅
Langues dans lesquelles les offres ou les demandes de participation peuvent être présentées: français 🗣️
Langues dans lesquelles les offres ou les demandes de participation peuvent être présentées: italien 🗣️
Le délai ci-dessous est exprimé en nombre de mois.
Délai minimum pendant lequel le soumissionnaire doit maintenir l'offre: 12
“To the extent that the law governing the bidding and awarding of this public contract is the French law, the contract notice published in French for this...”
To the extent that the law governing the bidding and awarding of this public contract is the French law, the contract notice published in French for this procurement contract is the only one to be considered if different from the present notice in English or from the notice in Italian, which are to be considered as courtesy translations.
Except for the Excel file and the reference table mentioned in III.1.2) and III.1.3) above respectively, there is no procurement documents available to the candidates. Interested candidates will only have to provide, before the deadline mentioned in IV.2.2) above, a candidate dossier including all the documents and information described above. Candidates will have to submit their bid solely via the dematerialisation platform, at the following address: https://telt.achatpublic.com/accueil/
Each transmission will be associated to a certified receipt date and it will produce an electronic receipt. The application may include a backup copy, delivered by hand against receipt or sent by express mail with acknowledgement of receipt to the address provided in I.1). All bids, including all backup copies, which are delivered after the date and hour specified will be declared as beyond the deadline and rejected. It is up to the candidates to verify and make sure that their dossier has arrived before the deadline.
Selected candidates shall receive a tender file whereby they shall be invited to submit their bids within a specified timeframe. Thereafter, the successful tenderer of each lot shall be chosen after negotiation, where necessary. It is hereby understood that, pursuant to article R.2161-23 of the Public Procurement Code, TELT reserves the right not to negotiate with all bidders, and to award the contract on the basis of the initial tenders. In case of negotiation, TELT reserves the right to gradually restrict the number of bidders allowed to negotiate as the negotiation phases unfold.
Tenders may be submitted for 1 or 2 lots. Where appropriate, both lots may be awarded to the same bidder after a separate analysis of each lot.
This contract is subject to:
— Italian law No 191/2009 pertaining to construction work items with regard to procedures for financing of the project by the Italian State; these rules will conform to European Union laws and regulations,
— the rules on the fight against Mafia infiltrations agreed by the French and Italian governments and brought into force via the Contract Regulation approved by the CIG (Inter-Governmental Commission), published in France as part of Decree No 2017-432 of 5.4.2017 and in force since 9.4.2018, in its updates. As such, the CUP and CIG codes of this public contract are as follows: CUP: C11J05000030001; CIG: Z2727BDB1C.
The successful tenderer of each lot of this procurement contract agrees to respect TELT’s code of ethics (freely available from the following address: http://www.telt-sas.com/fr/statut-code-ethique-accords), and also ensures that it is observed by its employees, co-contractors and subcontractors.
Finally, in accordance with article R.2185-1 of the Public Procurement Code, candidates and bidders are reminded that the tender can be withdrawn, at any moment of the procedure, up until the signing of the contract. In this case, bidders do not have any right to sign the contract, or to be reimbursed for the expenses they incurred as part of their application. The tender can be withdrawn by the Contracting Entity because of economic, legal, or technical reasons, or following a decision of the 2 States.
Afficher plus Organe de révision
Nom: Tribunal administratif de Grenoble
Adresse postale: 2 place de Verdun — BP 1135
Commune postale: Grenoble
Code postal: 38022
Pays: France 🇫🇷
Téléphone: +33 476420000📞
Courrier électronique: greffe.ta-grenoble@juradm.fr📧
Fax: +33 476422269 📠
URL: http://grenoble.tribunal-administratif.fr🌏 Procédure d'examen
Informations précises sur le(s) délai(s) des procédures d'examen:
“Applicable appeal procedures are:
— the pre-contractual interlocutory procedure (article L. 551-5 of the French Administrative Justice Code), which can be...”
Informations précises sur le(s) délai(s) des procédures d'examen
Applicable appeal procedures are:
— the pre-contractual interlocutory procedure (article L. 551-5 of the French Administrative Justice Code), which can be started before the signing of the public works contract,
— the contractual interlocutory procedure (article L. 551-13 of the French Administrative Justice Code), which can be started within 31 days from the publication of an award notice on the OJEU or within 6 months from the day after the conclusion of the public tender if no award notice is published,
— an appeal contesting the validity of the contract or of some of its advertising clauses in front of a litigation judge, which can be lodged within 2 months following all adequate advertising measures.
Afficher plus Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Nom: Tribunal administratif de Grenoble
Adresse postale: 2 place de Verdun — BP 1135
Commune postale: Grenoble
Code postal: 38022
Pays: France 🇫🇷
Téléphone: +33 476420000📞
Courrier électronique: greffe.ta-grenoble@juradm.fr📧
Fax: +33 476422269 📠
URL: http://grenoble.tribunal-administratif.fr🌏
Source: OJS 2019/S 124-303963 (2019-06-26)
Informations complémentaires (2019-08-19) Pouvoir adjudicateur Nom et adresse
Nom: Tunnel Euralpin Lyon-Turin SAS
Informations complémentaires Référence de l'avis original
Numéro de l'avis au JO S: 2019/S 124-303963
Changements Texte à corriger dans l'avis original
Numéro de section: IV.2.2)
Emplacement du texte à modifier: Time limit for receipt of tenders or requests to participate
Ancienne valeur
Date: 2019-09-16 📅
L'heure: 14:00
Nouvelle valeur
Date: 2019-09-25 📅
L'heure: 14:00
Source: OJS 2019/S 162-399415 (2019-08-19)
Avis d'attribution de marché (2023-12-08) Pouvoir adjudicateur Nom et adresse
Adresse postale: Bâtiment LINKLAB - 455 chemin de la Cassine - BP 20803
Commune postale: Chambery cedex
Code postal: 73008
Objet Champ d'application du marché
Titre:
“Construction of the base tunnel of the Lyon-Turin Railway Link Cross Border Section from the access sites onthe Italian side and reuse of excavated earth...”
Titre
Construction of the base tunnel of the Lyon-Turin Railway Link Cross Border Section from the access sites onthe Italian side and reuse of excavated earth and rocks
T13
Afficher plus
Brève description:
“Under the new Lyon-Turin railway link project, TELT company, as a contracting entity, is the public developer incharge of building and managing the...”
Brève description
Under the new Lyon-Turin railway link project, TELT company, as a contracting entity, is the public developer incharge of building and managing the cross-border section of the future infrastructure.
The aim of this public procurement contract is to carry out construction works on operational worksites n.3 (boring of the base tunnel from the Chiomonte site, direction Susa), n.4 (boring of the base tunnel from the Chiomonte site, direction France) and n.10 (reclamation of the earth and rocks excavated from all sites on Italian territory).
Each lot of this public procurement contract is a mixed single-contractor framework contract, i.e. a framework contract with purchase orders and follow-on contracts.
Afficher plus Informations sur les lots
Ce contrat est divisé en lots ✅ Description
Site principal ou lieu d'exécution: Communes of Chiomonte and Salbertrand
Description du marché:
“The works in this lot 1 include the transfer of existing structures (in particular the Maddalena 1 gallery andits installations, as well as all areas and...”
Description du marché
The works in this lot 1 include the transfer of existing structures (in particular the Maddalena 1 gallery andits installations, as well as all areas and installations at the Chiomonte site) and the construction of all futurestructures for the base tunnel, each tube being approximately 9.5 km long, from the boundaries of operational worksite 5 (CO5: boring of the base tunnel from the Villarodin-Bourget/Modane drift) up to the East entrance ofthe base tunnel in Susa.
The works that may be carried out by means of purchase orders are as follows:
- preparatory site works in the Colombera zone to extend the present La Maddalena area on the left bank of the Clarea river (fences, security installations, earthwork, backfilling, interface development, electric power supply, site ventilation, ancillary installations, living quarters, areas for temporary storage of excavation materials, etc.);
- construction surveys for tunnel structures;
- construction surveys and performance of all environmental surveillance and materials checking services;
- work systems and security costs according to the legislative decree 81/08;
- construction of the structures at the entrance to the Maddalena 2 decline;
- boring of the Maddalena 2 decline by TBM;
- construction by conventional method of the cavern used to assemble the TBM to excavate the odd line of thebase tunnel;
- excavation by conventional method of the Maddalena 1 - Clarea security area interconnection tunnel, and of the Maddalena 2 - Clarea security area interconnection tunnel;
- excavation by TBM of the two base tunnel tubes (even and odd lines);
- construction of the Clarea security area and of the caverns to assembly the TBMs for the CO5 operationalworksite;
- transport of excavated materials to the Salbertrand reclamation site;
- construction of the facility to prefabricate tunnel segments in the Salbertrand area, prefabrication and transportation of segments to line the two tubes of the base tunnel;
- construction of the Maddalena 1 bis tunnel to store the greenstone;
- final securing of the excavated greenstone for the construction of the base tunnel, in the Maddalena 1 and Maddalena 1 bis tunnels;
- construction of the structures at the East entrance of the base tunnel in Susa;
- winding down of the work site and renovation of the sites in the La Maddalena and Salbertrand areas.
The works that may be performed by means of follow-on contracts (launched or not depending on the CO5 completion date) consist of so-called “counter-attack” services for the excavation of the base tunnel on the La Clarea site towards France, which may include all or part of the following services:
- construction surveys for the counter-attack operation, including moving the caverns to dismantle the TBMsused for the CO5 operational worksite;
- excavation of the base tunnel as part of the counter-attack.
Follow-on contracts may as well allow for civil works to be carried out to construct tunnel structures that will interface with future equipment contracts.
The scope of this "Operational worksite 3/4" lot may undergo minor changes at the limits of "Operational worksite 5" to the West, based on the actual progress of each worksite and the need to comply with the projected project implementation programme schedule.
Afficher plus Critères d'attribution
Critère de qualité (nom): Technical value
Critère de qualité (pondération): 45
Prix (pondération): 55
Description
Informations complémentaires:
“The framework contract for this lot 1 will be concluded without a minimum and maximum amount.
A contractually binding performance deadline will be set for...”
Informations complémentaires
The framework contract for this lot 1 will be concluded without a minimum and maximum amount.
A contractually binding performance deadline will be set for each purchase order or follow-on contract.
Procédure Informations sur l'accord-cadre
La passation de marché implique l'établissement d'un accord-cadre
Informations administratives
Publication précédente concernant cette procédure: 2019/S 124-303963
Attribution du marché
1️⃣
Numéro de contrat: 1
Numéro d'identification du lot: 1
Titre:
“Operational worksites 3 and 4 (CO3 and CO4): construction of the base tunnel on the Italian side from the Chiomonte site, by TBM (CO3) and conventional method (CO4)”
Titre
Operational worksites 3 and 4 (CO3 and CO4): construction of the base tunnel on the Italian side from the Chiomonte site, by TBM (CO3) and conventional method (CO4)
Afficher plus
Date de conclusion du contrat: 2023-11-24 📅
Informations sur les appels d'offres
Nombre d'offres reçues: 4
Le contrat a été attribué à un groupe d'opérateurs économiques ✅ Nom et adresse du contractant
Nom: Itinera spa
Adresse postale: Via Balustra 15
Commune postale: Tortona
Code postal: 15057
Pays: Italie 🇮🇹
Région: Italia 🏙️
Le contractant est une PME
Nom: GHELLA S.p.A
Adresse postale: Via Pietro Borsieri 2/a
Commune postale: Rome
Code postal: 00195
Nom: Spie batignolle genie civil
Adresse postale: 30 Avenue du General Gallieni
Commune postale: Nanterre
Code postal: 92023
Pays: France 🇫🇷
Région: France🏙️ Information sur la valeur du contrat/lot (hors TVA)
Valeur totale du contrat/lot: EUR 1099425218.27 💰
Informations complémentaires Organe de révision
Nom: Administrative Court of Grenoble
Adresse postale: 2 place de Verdun - BP 1135
Procédure d'examen
Informations précises sur le(s) délai(s) des procédures d'examen:
“Applicable appeal procedures are:
- the contractual interlocutory procedure (article L.551-13 of the French Administrative Justice Code), which canbe...”
Informations précises sur le(s) délai(s) des procédures d'examen
Applicable appeal procedures are:
- the contractual interlocutory procedure (article L.551-13 of the French Administrative Justice Code), which canbe started within 31 days from the publication of an award notice on the OJEU or within 6 months from the dayafter the conclusion of the public tender if no award notice is published;
- an appeal contesting the validity of the contract or of some of its advertising clauses in front of a litigation judge, which can be lodged within 2 months following all adequate advertising measures.
Afficher plus Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Nom: Administrative Court of Grenoble
Adresse postale: 2 place de Verdun - BP 1135
Source: OJS 2023/S 240-753973 (2023-12-08)