Transportation and installation of the Offshore wind turbines on Courseulles-sur-Mer, Fécamp and Saint-Nazaire's offshore wind farms

Eolien Maritime France (Subsidiary of EDF EN France and DONG Energy Power Holding)

The scope of work consists of the load-out, transportation from assembly hubs to the Offshore Site and the installation of approximately 238 Wind Turbines Generators split in approximately 83 for Fécamp, approximately 75 for Courseulles-sur-mer, approximately 80 for St-Nazaire wind farms.

Date limite

Le délai de réception des offres était de 2014-12-15. L'appel d'offres a été publié le 2014-11-05.

Qui ?

• Eolien Maritime France (Subsidiary of EDF EN France and DONG Energy Power Holding)

Qu'est-ce que c'est ?

• Aérogénérateurs › Ferme éolienne
• Aérogénérateurs › Générateurs à turbines éoliennes
• Services offshore › Services d'installation offshore
• Travaux de construction de centrales électriques › Installations à énergie éolienne
• Turbines et moteurs › Installations de turbines

Où ?

Historique des marchés publics

Date	Document
2014-11-05	Avis de marché

Avis de marché (2014-11-05)
Objet
Champ d'application du marché
Titre: Services d'installation offshore
Quantité ou étendue:

The scope of work consists of the load-out, transportation from assembly hubs (expected to be located in St-Nazaire harbor for the St-Nazaire project and a harbor in Normandy for the Fécamp and Courseulles-sur-Mer projects) to the corresponding Offshore Sites and the installation of approximately 238 WTGs, approximately split in 83 for Fécamp, approximately 75 for Courseulles sur-Mer, approximately 80 for St-Nazaire projects and shall include Project management, administration and control, engineering, procurement, fabrication, testing, mobilization, load-out, transportation, installation on site, stacking completion, demobilization and installation as-built and final documentation.The Wind Turbines Generators components are mainly the tower (approximately 400 t and 80 m high), the 3 blades (approximately 75 m length and 30 t each), the nacelle/rotor assembly (approximately 400 t) with the hub high at approximately 105 m.

Métadonnées de l'avis
Langue originale: anglais 🗣️
Type de document: Avis de marché
Nature du marché: Marché de travaux
Réglementation: Union européenne, avec participation des pays de l'AMP
Vocabulaire commun pour les marchés publics (CPV)
Code: Services d'installation offshore 📦

Procédure
Type de procédure: Procédure négociée
Type de soumission: Soumission pour tous les lots
Critères d'attribution
Offre la plus économique

Pouvoir adjudicateur
Identité
Pays: France 🇫🇷
Type de pouvoir adjudicateur: Service d'utilité publique
Nom du pouvoir adjudicateur: Eolien Maritime France (Subsidiary of EDF EN France and DONG Energy Power Holding)
Adresse postale: Coeur Defense — Tour B — 100 Esplanade du General De Gaulle
Code postal: 92932
Commune postale: Paris La Défense
Contact
Adresse Internet: http://www.edf-energies-nouvelles.com 🌏
Courrier électronique: procurement@edf-en.com 📧
Téléphone: +33 140905080 📞

Référence
Dates
Date d'envoi: 2014-11-05 📅
Date limite de soumission: 2014-12-15 📅
Date de publication: 2014-11-08 📅
Identifiants
Numéro d'avis: 2014/S 216-382898
Numéro JO-S: 216
Informations complémentaires

A paper version of the documents and the electronic version on a CD or USB key shall be sent to the Contact and postal address of section I.1. All the documents shall be provided in a sealed envelop with the reference of the JOUE contract notice and the object of the contract. The Contract will be governed and ruled by the French Law.

Objet
Champ d'application du marché
Brève description:

Numéro du lot: 1
Intitulé du lot: Transportation and installation of the Offshore wind turbines on for Courseulles-sur-Mer
Brève description:

The scope of work consists of the load-out, transportation from assembly hub to the Offshore Site and the installation of approximately 75 Wind Turbines Generators for Courseulles-sur-mer wind farm.

Quantité ou étendue:

The scope of work consists of the load-out, transportation from assembly hub (expected to be located in a harbor in Normandy for Courseulles-sur-Mer project) to the corresponding Offshore Site and the installation of approximately 75 Wind Turbines Generators.

Shall be included: Project management, administration and control, engineering, procurement, fabrication, testing, mobilization, load-out, transportation, installation on site, stacking completion, demobilization and installation as-built and final documentation.

The Wind Turbines Generators components are mainly the tower (approximately 400 t and 80 m high), the 3 blades (approximately 75 m length and 30 t each), the nacelle/rotor assembly (approximately 400 t) with the hub high at approximately 105 m.

Durée de l'accord: 60 mois
Numéro du lot: 2
Intitulé du lot: Transportation and installation of the Offshore wind turbines on Fécamp offshore wind farm
Brève description:

The scope of work consists of the load-out, transportation from assembly hub to the Offshore Site and the installation of approximately 83 Wind Turbines Generators for Fécamp wind farm.

Quantité ou étendue:

The scope of work consists of the load-out, transportation from assembly hub (expected to be located in a harbor in Normandy for the Fécamp project) to the corresponding Offshore Site and the installation of approximately 83 Wind Turbines Generators.

Numéro du lot: 3
Intitulé du lot: Transportation and installation of the Offshore wind turbines for Saint-Nazaire wind farm
Brève description:

The scope of work consists of the load-out and transportation from assembly hub to the Offshore Site and the installation of approximately 80 Wind Turbines Generators for St Nazaire wind farm.

Quantité ou étendue:

The scope of work consists of the load-out, transportation from assembly hub (expected to be located in St-Nazaire harbor for the St-Nazaire project) to the corresponding Offshore Site and the installation of approximately 80 Wind Turbines Generators.

Les variantes sont acceptées ✅
Quantité ou étendue:

Lieu d'exécution
Site principal ou lieu d'exécution: Location of Fécamp, Courseulles-sur-Mer, Saint-Nazaire offshore wind farms.

Informations juridiques, économiques, financières et techniques
Conditions de participation
Habilitation à exercer l'activité professionnelle:

— Legal form and registration in a commercial register,

— Corporate ownership and Parent Company (if any),

— Corporate headquarters,

— List of worldwide locations (subsidiaries, affiliates, joint ventures, distributors) specifying the type of functionality (production, service, sales),

— An administration statement of the company that the work will be achieved by regular workers, according to the laws in effect,

— Attestation of lack of conviction for the last five years for professional misconduct of either the company or its managers.

In particular, may not tender:

1) those Candidates who have, within the last five years, been handed down a final sentence for one of the offences provided for in Articles 222-38, 222-40, 226-13, 313-1 to 313-3, 314-1 to 314-3, 324-1 to 324-6,413-9 to 413-12, 421-1 to 421-2-3, subparagraph two of Article 421-5, Article 433-1, subparagraph two of Article 433-2, subparagraph eight of Article 434-9, subparagraph two of Article 434-9-1, Articles 435-3, 435-4, 435-9,435-10, 441-1 to 441-7, 441-9, 445-1 and 450-1 of the French Penal Code, Article 1741 of the French General Tax Code and Articles L. 2339-2 to L. 2339-4, L. 2339-11-1 to L. 2339-11-3 of the French Defense Code and L.317-8 of the French Interior Security Code.

2) those Candidates who have, within the last five years, been handed down a sentence listed on Report n° 2 of the Criminal Records Bureau for the offences referred to in Articles L. 8221-1, L. 8221-3, L. 8221-5, L.8231-1, L. 8241-1, L. 8251-1 and L 8251-2 of the French Labour Code.

3) those Candidates subject to the compulsory liquidation proceedings provided for in Article L. 640-1 of the French Commercial Code, those individuals whose personal bankruptcy has been pronounced under Articles L.653-1 to L. 653-8 of the same Code as well as those persons subject to equivalent proceedings under a foreign law jurisdiction. Candidates admitted to the compulsory reorganisation proceedings laid down by Article L. 631-1 of the French Commercial Code or to equivalent proceedings under a foreign law jurisdiction must provide evidence that they have been authorised to continue their activities throughout the foreseeable term of execution of the contract.

4) those Candidates who, on 31 December of the year prior to that during which the tender is launched, had not fulfilled their obligations in terms of tax and social security declarations or had not paid the tax and contributions payable on that date. However, the following shall be regarded as eligible Candidates: those Candidates who, on 31 December of the year prior to that during which the tender is launched, had not paid the various amounts due on that date or provided any guarantees, but who had, before the date of the launch of the tender and without any enforcement measures having been taken by the accountant or the agency responsible for collection, either paid the said amounts or provided guarantees deemed sufficient by the accountant or the agency responsible for collection. Individuals who are legal or de facto directors of a legal entity that does not satisfy the conditions provided for in this subparagraph may not personally tender for a contract. In order to provide evidence that it is not in one of the situations cited in points 1) to 4) above, the Candidate must furnish a sworn statement, dated and signed.

These conditions are applicable to the Candidates and to each of the members of a group wishing to tender as a single Candidate.

Situation économique et financière:

A1. Ownership and corporate structure. If the company is a subsidiary, the name of the parent company and ultimate parent company must be stated as well as the name of a French representative, if any.

— Last 3 financial year's turnover, EBIT, and number of employees in total, as well as for the respective divisions,

— Annual report of the last financial year,

— Declaration that the company neither filled or is involved in insolvency proceedings and that insolvency proceedings have not been refused for lack of assets,

— Rating of an independent rating agency, whose rating is based on relevant European standards or equivalent criteria,

— Proof of valid liability insurance stating the sum insured.

Capacité technique et professionnelle:

In case of joint ventures or consortiums, Candidates shall indicate which partner has the relevant experience.

In case one or several activities listed below were subcontracted, subcontractor shall be described in Candidate's response.

For each of the following items, precise if the activity was solely performed by the Candidate's organization. If not, state which part was performed by a partner of a joint venture or of a consortium (and indicate the name of the partner), or if it was performed by a subcontractor (and indicate the name of the subcontractor). In this(ese) case(s), indicate the part (scope and percentage of the global contract) actually performed by the Candidate and the part (scope and percentage of global contract) performed by the partner and/or subcontractor.

The required information shall include as a minimum the following:

Item DE-1: Load-out, Transportation and installation of offshore wind turbines

Please provide the following documents/information:

— List of relevant contracts for the past ten (10) years, specifying for each contract:

Project name,

Name and address of client,

Contract award and completion dates,

Brief description of the works performed by the Candidate, with information regarding the codes and standards used for the Project,

Project Execution Plan,

Planning of the Project,

Organization chart.

Item DE-2: Design and engineering organization and capabilities

— Engineering management organization plan, team resources (permanent and contracted to be distinguished)

— Main disciplines of the design/engineering department and specialists (relevant for transportation and installation of offshore wind turbines),

— Management of multidisciplinary teams,

— Key employee skills, competencies and experiences you mobilized

— Engineering manual, list of engineering procedures, sample of procedures, Example of site specific assessment report,

— Engineering review process you apply to control and ensure that engineering is performed as per good industry practice, codes and standards,

Example of a HAZID report,

— Example of final project data book.

— Codes and standards currently used by the design department.

Item C-1: Procurement and fabrication experience related to all equipment and material necessary for the work such as but not limited to sea-fastening, grillage, lifting appuartenances, etc. Please provide the following document/information:

Typical or sample of seafastening design reports,

Planning of the supply activities.

Item C-2: Transportation and Installation experience related to offshore works for offshore wind turbines

Brief description of the works performed by the Candidate, with information regarding the codes and standards (US, European or others) used for the Project,

Planning of Load-out, Transport and Installation activities,

Details of methods and means of installation (methods, maritime spreads, logistics, soil conditions, product installed, etc.),

List of tools, marine assets, facility and / or technical equipments available to the tenderer for carrying out similar contracts.

Item M-1: Health and Safety management policy

— Copy of the Candidate's Health and Safety policy signed by a senior representative,

— Resume of the Candidate's Health and Safety policy showing its main objectives,

— Copy of OHSAS certificate or equivalent. Item M-1: Candidate's accidents statistics

— Your average statistics for the past three (3) years, including:

— Accidents frequency ratio,

— Accidents severity ratio,

Item M-2: Environmental management policy, environmental management system

— Copy of your Environmental policy signed by a senior representative,

— Summary of your Environmental policy showing its main objectives,

Item M-3: Quality management policy, quality management system

Please provide the following documents/information describing your quality system:

— Copy of your quality policy signed by a senior representative,

— Summary of your quality policy showing its main objectives, Resources and means used for similar projects.

Exécution du marché
Dépôts et garanties exigés:

These conditions will include securities such as an Advance Payment bond, an on-demand Performance bond and a Parent Company Guarantee.

Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent:

All the conditions will be detailed in the Contract documents attached to the invitation to tender. Payments will be made according to French law.

Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:

Candidates may be either single companies or consortium.

— In case the Candidate is a joint venture, the copy of the project of joint venture agreement is required,

— In case the Candidate is a consortium, a copy of the Memorandum Of Understanding or the project of contract of consortium has to be included. The consortium shall be jointly and severally liable (‘conjoint et solidaire’) or with a jointly liable leader (‘mandataire solidaire’),

— In case the Candidate is a single company, description of qualification and experience of subcontractors

(or potential subcontractors) to whom major parts of the works (such as design or installation) are going to be subcontracted, has to be included.

A Tenderer, which will submit an offer as member of a consortium or a joint venture, may not submit an offer as single company or with another consortium or joint venture.

Procédure
Durée de l’accord-cadre en mois: 60
Langues
Langue: anglais 🗣️
Autres langues:

Documents shall be provided in English; however, for the request to participate, Candidate may supply information in French, limited to some documents which are only available in French (notably, certificates related to III.2.1, III.2.2, III.2.3).

Pouvoir adjudicateur
Identité
Nom du pouvoir adjudicateur: Eoliennes Offshore des Hautes Falaises (subsiduary of Eolien Maritime France -subsiduary of EDF EN France and Dong Energy Power Holding and WPD Offshore GmbH
Commune postale: Paris la Defense cedex
Nom du pouvoir adjudicateur: Parc du Banc de Guerande (subsiduary of Eolien Maritime France -subsiduary of EDF EN France and Dong Energy Power Holding)
Eoliennes Offshore du Calvados (subsiduary of Eolien Maritime France -subsiduary of EDF EN France and Dong Energy Power Holding and WPD Offshore GmbH)
Adresse postale: Coeur Defense — Tour B — 100 Esplanade du General de Gaulle
Contact
Point de contact: Frédérique Richard
Courrier électronique: bertrand.allanic@edf-en.com 📧

Informations complémentaires
Organe de révision
Nom: Tribunal de Grande Instance de Nanterre
Adresse postale: 179-191 avenue Joliot-Curie
Commune postale: Nanterre cedex
Code postal: 92020
Pays: France 🇫🇷
Téléphone: +33 140971010 📞
Adresse Internet: http://www.ca-versailles.justice.fr 🌏
Informations sur les délais d'introduction des recours: 11 (eleven) calendar days from the date of contract award.
Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Nom: Eoliennes Offshore des Hautes Falaises- Bertrand Allanic
Adresse postale: Coeur Defense — Tour B — 100 Esplanade du General de Gaulle
Commune postale: Paris La Defense cedex
Code postal: 92932
Source: OJS 2014/S 216-382898 (2014-11-05)

Nouveaux marchés dans des catégories connexes 🆕

Services relatifs à l'industrie du pétrole et du gaz (2 nouveaux marchés)

Services onshore et offshore

Services offshore