Offshore Steel Monopile Foundations

Eolien Maritime France (Subsidiary of EDF EN and DONG Energy)

Lot N°1: Design, Engineering, Procurement, Construction and Installation of approximately 75 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Courseulles Wind Farm,
and/or
Lot N°2: Design, Engineering, Procurement, Construction and Installation of approximately 80 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Saint Nazaire Wind Farm.

Date limite

Le délai de réception des offres était de 2014-12-17. L'appel d'offres a été publié le 2014-10-10.

Qui ?

• Eolien Maritime France (Subsidiary of EDF EN and DONG Energy)

Qu'est-ce que c'est ?

Où ?

• Calvados
• Loire-Atlantique

Historique des marchés publics

Date	Document
2014-10-10	Avis de marché

Avis de marché (2014-10-10)
Objet
Champ d'application du marché
Titre: Installations à énergie éolienne
Quantité ou étendue:

Engineering, Procurement, Construction and Installation ofLot N°1: approximately 75 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Courseulles Wind Farm,and/or,Lot N°2: approximately 80 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Saint Nazaire Wind Farm,as well as, for both lots, the Engineering, Procurement, Construction and Installation of:— the appurtenances to the Transition Pieces (of the foundations) such as boat landing, access ladders and platform with related equipment (crane, lighting, MV/LV electrical equipments, etc.),— the stone works (soil preparation, scour protection if required),— the design, construction, operation and decommissioning of the onshore construction facilities if any.

Métadonnées de l'avis
Langue originale: anglais 🗣️
Type de document: Avis de marché
Nature du marché: Marché de travaux
Réglementation: Union européenne, avec participation des pays de l'AMP
Vocabulaire commun pour les marchés publics (CPV)
Code: Installations à énergie éolienne 📦

Procédure
Type de procédure: Procédure négociée
Type de soumission: Soumission pour un ou plusieurs lots
Critères d'attribution
Offre la plus économique

Pouvoir adjudicateur
Identité
Pays: France 🇫🇷
Type de pouvoir adjudicateur: Service d'utilité publique
Nom du pouvoir adjudicateur: Eolien Maritime France (Subsidiary of EDF EN and Dong Energy)
Adresse postale: Coeur Defense — Tour B — 100 Esplanade du General De Gaulle
Code postal: 92932
Commune postale: Paris La Défense
Contact
Adresse Internet: http://www.edf-energies-nouvelles.com 🌏
Courrier électronique: procurement@edf-en.com 📧
Téléphone: +33 140905080 📞

Référence
Dates
Date d'envoi: 2014-10-10 📅
Date limite de soumission: 2014-12-17 📅
Date de publication: 2014-10-15 📅
Identifiants
Numéro d'avis: 2014/S 198-350653
Numéro JO-S: 198
Informations complémentaires

A paper version of the documents and the electronic version on a CD or USB key shall be sent to the Contact and postal address of section I.1. All the documents shall be provided in a sealed envelop with the reference of the JOUE contract notice and the object of the contract. The Contract will be governed and ruled by the French Law.

Objet
Champ d'application du marché
Brève description:

and/or

Lot N°2: Design, Engineering, Procurement, Construction and Installation of approximately 80 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Saint Nazaire Wind Farm.

Numéro du lot: 1
Intitulé du lot: EPCI for Steel Monopile Foundations for Courseulles Sur Mer Offshore wind farm
Brève description:

Design, Engineering, Procurement, Construction and Installation of approximately 75 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Courseulles Wind Farm.

Quantité ou étendue: Approximately 75 Monopiles and associated Transition Pieces.
Durée de l'accord: 45 mois
Numéro du lot: 2
Intitulé du lot: EPCI for Steel Monopile Foundations for Saint Nazaire Offshore wind farm
Brève description:

Design, Engineering, Procurement, Construction and Installation of approximately 80 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Saint Nazaire Wind Farm.

Quantité ou étendue: Approximately 80 Monopiles and associated Transition Pieces.
Les variantes sont acceptées ✅
Quantité ou étendue:

Engineering, Procurement, Construction and Installation of

Lot N°1: approximately 75 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Courseulles Wind Farm,

and/or,

Lot N°2: approximately 80 Monopiles and associated Transition Pieces as Wind Turbine Generators foundations of the Saint Nazaire Wind Farm,

as well as, for both lots, the Engineering, Procurement, Construction and Installation of:

— the appurtenances to the Transition Pieces (of the foundations) such as boat landing, access ladders and platform with related equipment (crane, lighting, MV/LV electrical equipments, etc.),

— the stone works (soil preparation, scour protection if required),

— the design, construction, operation and decommissioning of the onshore construction facilities if any.

Lieu d'exécution
Site principal ou lieu d'exécution:

Location of the Courseulles sur Mer Offshore Wind Farm ( Lot N°1 ) and/or location of the Saint Nazaire Offshore Wind Farm ( Lot N°2 ).

Informations juridiques, économiques, financières et techniques
Conditions de participation
Habilitation à exercer l'activité professionnelle:

— Legal form and registration in a commercial register,

— Corporate ownership and Parent Company (if any),

— Corporate headquarters,

— List of worldwide locations (subsidiaries, affiliates, joint ventures, distributors) specifying the type of functionality (production, service, sales),

— An administration statement of the company that the work will be achieved by regular workers, according to the laws in effect.

In particular, may not tender:

1) those Candidates who have, within the last 5 years, been handed down a final sentence for one of the offences provided for in Articles 222-38, 222-40, 226-13, 313-1 to 313-3, 314-1 to 314-3, 324-1 to 324-6,413-9 to 413-12, 421-1 to 421-2-3, subparagraph two of Article 421-5, Article 433-1, subparagraph two of Article 433-2, subparagraph eight of Article 434-9, subparagraph two of Article 434-9-1, Articles 435-3, 435-4, 435-9,435-10, 441-1 to 441-7, 441-9, 445-1 and 450-1 of the French Penal Code, Article 1741 of the French General Tax Code and Articles L. 2339-2 to L. 2339-4, L. 2339-11-1 to L. 2339-11-3 of the French Defense Code and L.317-8 of the French Interior Security Code.

2) those Candidates who have, within the last five years, been handed down a sentence listed on Report n

° 2 of the Criminal Records Bureau for the offences referred to in Articles L. 8221-1, L. 8221-3, L. 8221-5, L.8231-1, L. 8241-1, L. 8251-1 and L 8251-2 of the French Labour Code.

3) those Candidates subject to the compulsory liquidation proceedings provided for in Article L. 640-1 of the French Commercial Code, those individuals whose personal bankruptcy has been pronounced under Articles L.653-1 to L. 653-8 of the same Code as well as those persons subject to equivalent proceedings under a foreign law jurisdiction. Candidates admitted to the compulsory reorganisation proceedings laid down by Article L. 631-1 of the French Commercial Code or to equivalent proceedings under a foreign law jurisdiction must provide evidence that they have been authorised to continue their activities throughout the foreseeable term of execution of the contract.

4) those Candidates who, on 31 December of the year prior to that during which the tender is launched, had not fulfilled their obligations in terms of tax and social security declarations or had not paid the tax and contributions payable on that date. However, the following shall be regarded as eligible Candidates: those Candidates who, on 31 December of the year prior to that during which the tender is launched, had not paid the various amounts due on that date or provided any guarantees, but who had, before the date of the launch of the tender and without any enforcement measures having been taken by the accountant or the agency responsible for collection, either paid the said amounts or provided guarantees deemed sufficient by the accountant or the agency responsible for collection. Individuals who are legal or de facto directors of a legal entity that does not satisfy the conditions provided for in this subparagraph may not personally tender for a contract. In order to provide evidence that it is not in one of the situations cited in points 1) to 4) above, the Candidate must furnish a sworn statement, dated and signed.

These conditions are applicable to the Candidates and to each of the members of a group wishing to tender as a single Candidate.

Situation économique et financière:

A1. Ownership and corporate structure. If the company is a subsidiary, the name of the parent company and ultimate parent company must be stated as well as the name of a French representative, if any.

— Last 3 financial year's turnover, EBIT, and number of employees in total, as well as for the respective divisions,

— Annual report of the last financial year,

— Declaration that the company neither filled or is involved in insolvency proceedings and that insolvency proceedings have not been refused for lack of assets,

— Rating of an independent rating agency, whose rating is based on relevant European standards or equivalent criteria,

— Proof of valid liability insurance stating the sum insured.

Capacité technique et professionnelle:

In case of joint ventures or consortiums, Candidates shall indicate which partner has the relevant experience.

In case one or several activities listed below were subcontracted, relevant experience with regard to such subcontractor shall be described in Candidate's response. For each of the following items, precise if the activity was solely performed by the Candidate's organization. If not, state which part was performed by a partner of a joint venture or of a consortium (and give name of the partner), or if it was performed by a subcontractor (and give name of the subcontractor). In this(ese) case(s), indicate the part (scope and percentage of the global contract) actually performed by the Candidate and the part (scope and percentage of global contract) performed by the partner and/or subcontractor.

The required information shall include as a minimum the following:

Item G-1: General Engineering, Procurement, Construction and Installation contractor experience

— List of relevant contracts for the past ten (10) years, specifying for each contract:

— Project identification,

— Name and address of client,

— Contract award and completion dates,

— Brief description of the works performed by the Candidate, with information regarding the codes and standards (US, European or others) used for the Project

— Price of contract or, in case of consortium and/or substantial parts were subcontracted, part of contract implemented by the Candidate.

Item DE-1: Design and engineering experience relating to marine or offshore works including special large steel foundations (such as steel Foundations for Offshore Wind Turbines,bridge piles at sea or foundations for oil and gas platforms or similar) and associated works (soil preparation, scour protection, dredging if any)

— List of relevant contracts (i.e. part of the contract performed by the entity in charge of the design and/or engineering) for the past ten (10) years, specifying for each contract

— Project short description, including capacity and dimensions of the foundations or works carried out, with information regarding the codes and standards (US, European or others) used for the Project,

— Details of relevant experience (such as description of cost control, doc control, planning and progress measurement, reporting, organisation management, others...)

Item DE-2: Engineering experience relating to the installation of marine or offshore works including special large steel foundations (such steel Foundations for Offshore Wind Turbines,or bridge piles at sea or foundations for oil and as platforms or similar) and associated works (such as soil preparation, scour protection, towing, heavy lifting, drilling, piling, cuttings disposal)

— List of relevant contracts (i.e. part of the contract performed by the entity in charge of the engineering) or the past ten (10) years, specifying for each contract:

— Project short description, including description of methods for installation, with information regarding the codes and standards (US, European or others) used for the Project,

— Details of relevant experience.

Item DE-3: Design and engineering organization and capabilities

— Engineering management organization, team resources (permanent and contracted to be distinguished) – Main disciplines, core of the design/engineering department and specialists (relevant for steel foundation design and marine and offshore works),

Codes and standards currently used by the design department,

— Engineering manual, list of engineering procedures, sample of procedures (such as HAZOP, HAZID, others...)

Item C-1: Manufacturing experience relating to marine or offshore structures including special steel foundations (such as steel Foundations for Offshore Wind Turbines or bridge piles at sea, or foundations for oil and gas platforms or similar)

List of relevant contracts for the past ten (10) years, specifying for each contract:

— Project short description, including volumes and characteristics of the steel structures, with information regarding the codes and standards (US, European or others) used for the Project— Details of methods and construction techniques, storages capacities

— Details of manufacturing techniques ( rolling, welding techniques ).

Item C-2: Installation experience relating to marine or offshore works including special large steel foundations (such as steel Foundations for Offshore Wind turbines or bridge piles at sea, or foundations for oil and gas platforms or similar) and associated works (soil preparation, scour protection, towing, heavy lifting, drilling, piling, cuttings disposal)

— Project short description, including characteristics of the installed structures, with information regarding the codes and standards (US, European, others) used for the Project

— Details of methods and means of installation and offshore organisation.

Item M-1: Health and Safety management policy

— Copy of the Candidate's Health and Safety policy signed by a senior representative,

— Resume of the Candidate's Health and Safety policy showing its main objectives,

— Copy of OHSAS certificate or equivalent.

Item M-2: Candidate's accidents statistics

— Candidates average statistics for the past three (3) years, including:

— Accidents frequency ratio,

— Accidents severity ratio,

Item M-3: Environmental management policy, environmental management system

— Copy of the Candidate's Environmental policy signed by a senior representative,

— Summary of the Candidate's Environmental policy showing its main objectives,

Item M-4: Quality management policy, quality management system

Documents describing the Candidate's quality system:

— Copy of the Candidate's quality policy signed by a senior representative,

— Summary of the Candidate's quality policy showing its main objectives,

— Resources and means used for similar projects.

Exécution du marché
Dépôts et garanties exigés:

These conditions will include securities such as an Advance Payment bond, an on-demand Performance bond and a Parent Company Guarantee.

Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent:

All the conditions will be detailed in the Contract documents attached to the invitation to tender.

Payments will be made according to French law.

Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:

Candidates may be either single companies or consortium.

— In case the Candidate is a joint venture, the copy of the project of joint venture agreement is required,

— In case the Candidate is a consortium, a copy of the Memorandum Of Understanding or the project of contract of consortium has to be included. The consortium shall be jointly and severally liable (‘conjoint et solidaire’) or with a jointly liable leader (‘mandataire solidaire’),

— In case the Candidate is a single company, description of qualification and experience of subcontractors (or potential subcontractors) to whom major parts of the works (such as design, installation, others...) are going to be subcontracted, has to be included.

A Tenderer, which will submit an offer as member of a consortium or a JV, may not submit an offer as single company or with another consortium or JV.

Procédure
Langues
Langue: anglais 🗣️
Autres langues:

Shall be provided in English; however, for the request to participate, Candidate may supply information in French, limited to some documents which are only available in French (notably, certificates related to III.2.1, III.2.2, III.2.3)

Pouvoir adjudicateur
Identité
Nom du pouvoir adjudicateur: Eoliennes Offshore du Calvados
Parc du Banc de Guérande
Adresse postale: Cœur Défense — Tour B — 100 Esplanade du Général de Gaulle
Contact
Point de contact: Eolien Maritime France
Arnaud Celliere or Frédérique Richard

Informations complémentaires
Organe de révision
Nom: Tribunal de Grande Instance de Nanterre
Adresse postale: 179-191 avenue Joliot-Curie
Commune postale: Nanterre
Code postal: 92020
Pays: France 🇫🇷
Téléphone: +33 140971010 📞
Adresse Internet: www.ca-versailles.justice.fr 🌏
Nom: Eolien Maritime France - Bernard GUITTON
Informations sur les délais d'introduction des recours: 11 (eleven) calendar days from the date of contract award.
Organisme responsable des procédures de médiation
Adresse postale: Coeur Défense — Tour B — 100 Esplanade du Général de Gaulle
Commune postale: Paris
Code postal: 92932
Téléphone: +33 140905080 📞
Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Nom: Greffe du Tribunal de Grande Instance
Adresse postale: 179 191 avenue Joliot Curie
Adresse Internet: http://www.ca-versailles.justice.fr 🌏
Source: OJS 2014/S 198-350653 (2014-10-10)

Nouveaux marchés dans des catégories connexes 🆕

Travaux de construction (>20 nouveaux marchés)

Travaux de construction complète ou partielle et travaux de génie civil (>20)

Travaux de construction d'usines, d'exploitations minières et d'unités de fabrication et de bâtiments pour l'industrie du pétrole et du gaz (15)

Travaux de construction de centrales électriques et de centrales thermiques (8)

Travaux de construction de centrales électriques (2)