2 lots: 1) UK 2211: HR airlocks for hinkley point (England) new nuclear power plant (twin-reactor site): 2 HR airlocks (personnal and emergency exit) for 1 unit. Total: 4 airlocks for 2 units. 2) PE 2211: HR airlocks for Penly (France) new nuclear power plant (single reactor site): 2 airlocks (personnal and emergency exit) for 1 unit

EDF SA - Acting in its own name and in the name and on behalf of its affiliated companies

The scope of works for the proposed contracts includes:
1) UK 2211: studies, supply, qualification, manufacturing, and associated controls, delivery, erection, commissioning and on-site testing for 4 airlocks for 2 units at Hinkley point new nuclear power plant (twin-reactor site) (2 airlocks per unit)
2) PE 2211: studies, supply, qualification, manufacturing, and associated controls, delivery, erection, commissioning and on-site testing for 2 airlocks for Penly 3 new nuclear power plant (single reactor site)
EPR HR airlocks are used for the traffic of the personnel as well as small equipments, whatever the state of the nuclear power pant, without affecting the containment of the enclosure. The personal HR airlock is erected in the reactor building at level +1,5m, the emergency exit HR airlock at level +19,5m. Both airlocks are identical. They are part of the third containment barrier.
Further information and details are filled in the appendix A of PQQ.

Date limite

Le délai de réception des offres était de 2011-03-03. L'appel d'offres a été publié le 2011-02-03.

Qui ?

• EDF SA - Acting in its own name and in the name and on behalf of its affiliated companies

Qu'est-ce que c'est ?

• Machines industrielles › Machines de production et d'utilisation de la puissance mécanique

Où ?

• France

Historique des marchés publics

Date	Document
2011-02-03	Avis de marché
2011-02-23	Informations complémentaires

Avis de marché (2011-02-03)
Objet
Champ d'application du marché
Titre: Machines de production et d'utilisation de la puissance mécanique
Quantité ou étendue:

Each nuclear unit includes 1 personal exit and 1 emergency exit HR airlocks.1) UK2211— Hinkley point nuclear power plant: 2 firm units: 4 airlocks,— option 1: other nuclear power plant in the UK: 1 optional unit (2 airlocks),— option 2: other nuclear power on the same site as option 1 or in a third site. (2 airlocks).2) PE 2221:PENLY 3 Nuclear Power Plant: 2 Airlocks.

Métadonnées de l'avis
Langue originale: anglais 🗣️
Type de document: Avis de marché
Nature du marché: Fournitures
Réglementation: Union européenne, avec participation des pays de l'AMP
Vocabulaire commun pour les marchés publics (CPV)
Code: Machines de production et d'utilisation de la puissance mécanique 📦

Procédure
Type de procédure: Procédure négociée
Type de soumission: Soumission pour un ou plusieurs lots
Critères d'attribution
Offre la plus économique

Pouvoir adjudicateur
Identité
Pays: France 🇫🇷
Type de pouvoir adjudicateur: Service d'utilité publique
Adresse postale: 20, place de la Défense
Code postal: 92050
Commune postale: Paris La Défense Cedex
Contact
Adresse Internet: http://www.edf.com 🌏
Courrier électronique: tony-f.gout@edf.fr 📧
Téléphone: +33 177491194 📞

Référence
Dates
Date d'envoi: 2011-02-03 📅
Date limite de soumission: 2011-03-03 📅
Date de publication: 2011-02-09 📅
Identifiants
Numéro d'avis: 2011/S 27-044598
Numéro JO-S: 27
Informations complémentaires

Contracts (are intended to be notified to one or 2 supplier(s) with one English contract (covering Uk project and associated options) and one French contract (covering Penly 3 project). Consequently, the suppliers should mention from the RFI stage on which lot they intend to tender. As described below the request for information is available on the Procurement portal. Awarding rules will be defined in the coming invitation to tender. EDF could ask during the tender stage to the tenderer to carry out a design case study, related to the process. In that case, suppliers who have submitted a technically compliant offer will receive a financial compensation. The effective realization of the works, object of the present contract notice, will be subject to the positive outcome of corresponding governemental and administrative authorizations, in UK and in France, and to the decision of EDF executive committee. We inform you that EDF Procurement Direction decided to generalise the practice of electronic call for bids (e-tenders) and opened the EDF Procurement portal (portail Achats). This concerns the publishing on-line on an Internet platform of all elements of the call for bids. Consulted suppliers are invited to publish their technical and financial offer on this platform. The objective of this evolution is to improve the productivity and the ability to react as well in EDF Procurement Direction as by the suppliers, while bringing additional guarantees in terms of equity of treatment, traceability and of confidentiality of the exchanges. For this goal, we invite you to become known from the buyers of the Procurement Direction by registering your company on the site of the Procurement portal (www.portail-achats.edf.com). For registering you will have to fulfill: — company data, — the details of account administrator. We draw your attention on the importance of the account administrator. This interlocutor will handle to manage all user profiles. A single account administrator is declared for one Siret number. — Every administrator and user has a log-in and a password. The confidential password is awarded by the system. It can be modified on the Procurement portal as often as the user wishes. You will find in joined appendix all the technical information relative to the Procurement portal. If needed, you can call the following phone number +33 811906438 (price of a local call), — For a EU company (except France), a single account administrator is declared by intracommunity VAT number. For a non EU company, a single account administrator is declared by Dun & Bradstreet number. Please be careful. Your application shall be submitted in the Procurement portal by answering free access request for information planned for that purpose (rfi_52827).

Informations complémentaires

Contracts (are intended to be notified to one or 2 supplier(s) with one English contract (covering Uk project and associated options) and one French contract (covering Penly 3 project).

Consequently, the suppliers should mention from the RFI stage on which lot they intend to tender. As described below the request for information is available on the Procurement portal.

Awarding rules will be defined in the coming invitation to tender.

EDF could ask during the tender stage to the tenderer to carry out a design case study, related to the process. In that case, suppliers who have submitted a technically compliant offer will receive a financial compensation.

The effective realization of the works, object of the present contract notice, will be subject to the positive outcome of corresponding governemental and administrative authorizations, in UK and in France, and to the decision of EDF executive committee.

We inform you that EDF Procurement Direction decided to generalise the practice of electronic call for bids (e-tenders) and opened the EDF Procurement portal (portail Achats).

This concerns the publishing on-line on an Internet platform of all elements of the call for bids.

Consulted suppliers are invited to publish their technical and financial offer on this platform. The objective of this evolution is to improve the productivity and the ability to react as well in EDF Procurement Direction as by the suppliers, while bringing additional guarantees in terms of equity of treatment, traceability and of confidentiality of the exchanges.

For this goal, we invite you to become known from the buyers of the Procurement Direction by registering your company on the site of the Procurement portal (www.portail-achats.edf.com). For registering you will have to fulfill:

— company data,

— the details of account administrator.

We draw your attention on the importance of the account administrator. This interlocutor will handle to manage all user profiles. A single account administrator is declared for one Siret number.

— Every administrator and user has a log-in and a password. The confidential password is awarded by the system. It can be modified on the Procurement portal as often as the user wishes. You will find in joined appendix all the technical information relative to the Procurement portal. If needed, you can call the following phone number +33 811906438 (price of a local call),

— For a EU company (except France), a single account administrator is declared by intracommunity VAT number. For a non EU company, a single account administrator is declared by Dun & Bradstreet number.

Please be careful.

Your application shall be submitted in the Procurement portal by answering free access request for information planned for that purpose (rfi_52827).

Objet
Champ d'application du marché
L’avis concerne: Public_contract
Brève description:

The scope of works for the proposed contracts includes:

1) UK 2211: studies, supply, qualification, manufacturing, and associated controls, delivery, erection, commissioning and on-site testing for 4 airlocks for 2 units at Hinkley point new nuclear power plant (twin-reactor site) (2 airlocks per unit)

2) PE 2211: studies, supply, qualification, manufacturing, and associated controls, delivery, erection, commissioning and on-site testing for 2 airlocks for Penly 3 new nuclear power plant (single reactor site)

EPR HR airlocks are used for the traffic of the personnel as well as small equipments, whatever the state of the nuclear power pant, without affecting the containment of the enclosure. The personal HR airlock is erected in the reactor building at level +1,5m, the emergency exit HR airlock at level +19,5m. Both airlocks are identical. They are part of the third containment barrier.

Further information and details are filled in the appendix A of PQQ.

Numéro du lot: 1
Intitulé du lot: -UK 2211 HR airlock
Brève description:

Studies, supply, manufacturing, transport, on-site storage, erection and industrial commissioning of 2 HR airlocks per unit of a nuclear plant (1 personal and 1 emergency exit), in the UK.

Quantité ou étendue:

Hinckley point nuclear power plant: 4 firm airlocks for HP3 & HP4 (2 airlocks per unit).

— option 1: other nuclear power plant in the UK: 1 optional unit,

— option 2: other nuclear power plant in the UK: 1 optional unit.

Scope is detailed in the PQQ.

Durée de l'accord: 174 mois
Informations complémentaires sur les lots:

Contract governed and ruled by the English law. Payment in GBP and/or in EUR. FIDIC Yellow Book based terms and conditions (English language). Staff acting on the construction sites must understand, speak, read and write English.

Numéro du lot: 2
Intitulé du lot: PE 2211 HR airlock
Brève description:

Studies, manufacturing, transport, on-site storage, erection and industrial commisioning of 2 HR airlocks (1 personal airlock and 1 emergency exit airlock) for the firm unit in Penly, France.

Quantité ou étendue: Penly 3 nuclear power plant (Penly lot): 1 firm unit: 2 airlocks.
Durée de l'accord: 60 mois
Informations complémentaires sur les lots:

The contract will be governed and ruled by the French Law.

Payment in Euros. EDF standard terms & conditions.

French technical specifications and terms & conditions will be contractual. English translations will be available for information only. Staff acting on the construction site must understand, pseak, read and write French.

Quantité ou étendue:

Each nuclear unit includes 1 personal exit and 1 emergency exit HR airlocks.

1) UK2211

— Hinkley point nuclear power plant: 2 firm units: 4 airlocks,

— option 1: other nuclear power plant in the UK: 1 optional unit (2 airlocks),

— option 2: other nuclear power on the same site as option 1 or in a third site. (2 airlocks).

2) PE 2221:

PENLY 3 Nuclear Power Plant: 2 Airlocks.

Description des options:

The options cover 2 possible additionnal nuclear power plant in the UK (possibly on the same site).

The options will be detailed in the ITT.

Numéro de référence: — Lot 1: UK 2211— Lot 2: PE 2211
Lieu d'exécution
Site principal ou lieu d'exécution:

1. UK 2211:

a) Hinckley point nuclear power plant, Somerset, England, Nuts UKK23;

b) Option for 1 or 2 other sites in the UK.

2. PE 2211:

— Penly 3 nuclear power plant (76 France) Nuts FR232.

Informations juridiques, économiques, financières et techniques
Conditions de participation
Habilitation à exercer l'activité professionnelle:

To be selected for the invitation to tender, the candidates shall answer and submit a pre-qualification questionnaire (PQQ), which is available on the portail Achats website (www.portail-achats.edf.com) as an attachement in request for information (rfi_52827).

This questionnaire and the candidatures will be analysed by EDF to assess the capabilities of potential bidders and select them for the ITT.

In addition to the documents required in the PQQ, the company shall provide:

— the administrative certificate proving that the company is up to date of its taxes payment,

— a certificate delivered by the organisation of covering certifying that the payment of the national insurance contributions is up to date taking into consideration payment (EEC) No 1408-71 of the 14.6.1971,

— a certificate on the honor which guarantees that works will be performed with employees legally employed, taking into consideration articles L143-3, L143-5 and L620-3 and article R341-36 of the French working law concerning the use of foreign workers or equivalent,

— a certificate from a insurance company certifying that it guaranteed the pecuniary consequences of civil responsibility,

— a certificate on the honor which guarantees, for the last 5 years, the absence of judgement registered on the bulletin N°2 of the police record for infringements aimed to Articles L324-9, L341-6, L125-1 and L125-3 of the French working law or equivalent.

When a document or a certificate is not issued by the country concerned, it can be replaced by a declaration under oath or a solemn declaration, made by the economic operator party with a legal or administrative authority, a notary or any other qualified authority of the state concerned.

These documents or certificates, if they are not written in French or English, must be accompanied by a translation in one of these language.

Cannot tender:

1) candidates who were the object, in the last 5 years, of a final judgement for one of the infringements envisaged by articles 222-38, 222-40, 313-1 to 313-3, 314-1 to 314-3, 324-1 to 324-6, 421-2-1, 421-5 second subparagraph, 433-1, 433-2 second subparagraph, 434-9 eighth subparagraph, 434-9-1 second subparagraph, 435-3, 435-4, 435-9, 435-10, 441-1 to 441-7, 441-8 first and second subparagraphs, 441-9, 445-1 and 450-1 of the French Penal Code, and by 1741 of the French General Tax Code.

2) candidates who were the object, in the last 5 years, of a judgement registered in the bulletin N°2 of the record for punishments for the infringements mentioned in articles L. 8221-1, L. 8221-3, L. 8221-5, L. 8231-1, L. 8241-1 and L. 8251-1 of the French working law;

3) candidates who are winding up according to the terms of article L640-1 of the Commercial Law, corporations legal entities whose personnel bankruptcy was marked within the meaning of articles L. 653-1 to L. 653-8 of the Commercial Law, as well as the people being the object of an equivalent procedure governed by a foreign law. Candidates admitted with the file for bankruptcy within the meaning of article L631-1 of the Commercial Law, or with an equivalent procedure governed by a foreign law, must justify that they were entitled to continue their activity during the foreseeable duration of the contract and must provide, to support their candidature, the copy of the judgements pronounced for this purpose;

4) Candidates who, on 31st December of the year preceding the one of the launching of the consultation, did not sign the declarations about the tax and social matter, or have not discharged the payable taxes and contributions on this date. However, are considered as in a regular situation candidates who, on the 31st of December of the year preceding the one of the launching of the consultation, had not discharged the contributions payable at this date nor generated guaranties, but who, before the launching of the consultation, and without any execution action from the entity responsible for recovery, have either discharged the above mentioned contributions or generated warranties which are estimated sufficient by the entity responsible for recovery. The physical persons which are directing by right or de facto an moral entity not complying with the conditions of this paragraph cannot be personally candidates for this market. In order to justify he is not in one of the positions listed above, the candidate must provide a dated and signed certificate on the honour. These conditions apply to candidates and to each member of the grouping.

Situation économique et financière:

The tenderer shall provide the last 3 financial results and income statements (for French companies, the tax bundle including at least the financial result pages 1 and 2, the income statement pages 3 and 4 and the appendices page 5, 8 and 11).

Depending on the lots he wants to tender upon, the tenderer shall have a minimum turnover per year for the last 3 years:

Lot 1: UK 2211 : 12 000 000 EUR.

Lot 2: PE 2211 : 12 000 000 EUR.

Lot 1 + lot 2: UK 2211 and PE 2211 : 24 000 000 EUR.

Capacité technique et professionnelle:

The applicant has to justify evidences about its technical abilities. The following information and formalities are necessary for evaluating if the requirements are met.

(if applicable):

1) ISO9001 (Vs2000), ISO 14001 (or equivalent), OHSAS 18001 (or equivalent) required.

2) Demonstrate your in-house or subcontracted capabilities for the implementation of 2 to 10 (depending on the number of lots tendered) airlocks, including:

— Design,

— Qualification,

— Supply of equipment,

— Manufacturing,

— Transportation,

— Erection,

— Commissioning.

Abilities demonstration could be made through examples of scope of work and contracts references, detail of project schedulling or other relevant information.

3) In case of bid onto the 2 lots (UK2211 and PE2211), demonstrate your in-house or subcontracted ability to build potentialy 4 airlocks at the same time. (2 units at the same time)

4) Demonstrate your in-house or subcontracted ability in calculating earthquake risks on the metal frames.

5) Demonstrate its capability to qualify components (for instance: seals) according to some demanding conditions.

6) To be able to communicate written and spoken in the French and the English language.

Exécution du marché
Dépôts et garanties exigés:

Financial guarantees will be required (deposits, financial retention, ...) and detailed in the ITT.

Principales conditions de financement et modalités de paiement et/ou référence aux dispositions pertinentes qui les régissent: It will be detailed in the ITT.
Forme juridique que devra revêtir le groupement d'opérateurs économiques attributaire du marché:

Grouping of economic operators can be considered. Their capabilities and references will be cumulated to be analyzed. Each operator will have to justify its legal and economic status.

Candidates may be either single companies or consortium.

In case the Candidate is a consortium/joint venture, a copy of the Momerandum of understanding or the contract of consortium/joint venture has to be presented. The form of the consortium/joint venture shall be joint and several.

Procédure
Langues
Langue: anglais 🗣️
français 🗣️

Pouvoir adjudicateur
Identité
Nom du pouvoir adjudicateur: EDF SA - Acting in its own name and in the name and on behalf of its affiliated companies
Activité principale: Electricity
Contact
Point de contact: Agence Achats Ingénierie CNEN
Tony Gout/Karim Bachri
Adresse Internet: www.edf.com 🌏
Adresse du profil d'acheteur: http://portail-achats.edf.com 🌏

Informations complémentaires
Organe de révision
Nom: Tribunal de Grande Instance de Paris
Adresse postale: 4 boulevard du Palais
Commune postale: Paris Cedex 01
Code postal: 75055
Pays: France 🇫🇷
Téléphone: +33 144325151 📞
Adresse Internet: http://www.tgi-paris-justice.fr 🌏
Service auprès duquel des informations sur la procédure de recours peuvent être obtenues
Identique à : Organe de révision
Source: OJS 2011/S 027-044598 (2011-02-03)

Informations complémentaires (2011-02-23)
Objet
Métadonnées de l'avis
Type de document: Informations complémentaires

Référence
Dates
Date d'envoi: 2011-02-23 📅
Date de publication: 2011-02-25 📅
Identifiants
Numéro d'avis: 2011/S 39-062866
Se réfère à l'avis: 2011/S 27-044598
Numéro JO-S: 39
Source: OJS 2011/S 039-062866 (2011-02-23)

Nouveaux marchés dans des catégories connexes 🆕

Machines industrielles (>20 nouveaux marchés)

Machines de production et d'utilisation de la puissance mécanique (16)